UNITED STATES

SECURITIES AND EXCHANGE COMMISSION

WASHINGTON, D.C. 20549

FORM 10-Q

(Mark One)


	☒	QUARTERLY REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934

For the quarterly period ended March 31, 2021

☐

TRANSITION REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934

For the transition period from_____________ to _____________

Commission File Number 001-08546

TRINITY PLACE HOLDINGS INC.

(Exact Name of Registrant as Specified in Its Charter)


Delaware	22-2465228
(State or Other Jurisdiction of	(I.R.S. Employer Identification No.)
Incorporation or Organization)

340 Madison Avenue, New York, New York	10173
(Address of Principal Executive Offices)	(Zip Code)

(212) 235-2190

(Registrant’s Telephone Number, Including Area Code)

Securities registered pursuant to Section 12(b) of the Act:


Title of Each Class	Trading Symbol	Name of each exchange on which registered
Common Stock $0.01 Par Value Per Share	TPHS	NYSE American

Indicate by check mark whether the registrant: (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days. Yes ⌧ No ◻

Indicate by check mark whether the registrant has submitted electronically every Interactive Data File required to be submitted pursuant to Rule 405 of Regulation S-T (Section 232.405 of this chapter) during the preceding 12 months (or for such shorter period that the registrant was required to submit such files). Yes ⌧ No ◻

Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, a smaller reporting company, or an emerging growth company. See the definitions of “large accelerated filer,” “accelerated filer,” “smaller reporting company,” and “emerging growth company” in Rule 12b-2 of the Exchange Act.

Large Accelerated Filer ◻

Accelerated Filer ☐

Non-Accelerated Filer ☒

Smaller Reporting Company ☒

Emerging Growth Company ☐

If an emerging growth company, indicate by check mark if the registrant has elected not to use the extended transition period for complying with any new or revised financial accounting standards provided pursuant to Section 13(a) of the Exchange Act. ◻

Indicate by check mark whether the registrant is a shell company (as defined in Rule 12b-2 of the Exchange Act). Yes ☐

No ⌧

Indicate by check mark whether the registrant has filed all documents and reports required to be filed by Sections 12, 13 or 15(d) of the Securities Exchange Act of 1934 subsequent to the distribution of securities under a plan confirmed by a court. Yes ⌧ No ◻

As of May 12, 2021, there were 32,455,568 shares of the registrant’s common stock, par value $0.01 per share, outstanding.

Table of Contents

INDEX


		PAGE NO.
PART I.	FINANCIAL INFORMATION	3

Item 1.	Condensed Consolidated Financial Statements	3

	Consolidated Balance Sheets as of March 31, 2021 (unaudited) and December 31, 2020 (audited)	3

	Consolidated Statements of Operations and Comprehensive Loss for the three months ended March 31, 2021 and 2020 (unaudited)	4

	Consolidated Statements of Stockholders' Equity for the three months ended March 31, 2021 and 2020 (unaudited)	5

	Consolidated Statements of Cash Flows for the three months ended March 31, 2021 and 2020 (unaudited)	6

	Notes to Condensed Consolidated Financial Statements (unaudited)	7

Item 2.	Management’s Discussion and Analysis of Financial Condition and Results of Operations	26

Item 3.	Quantitative and Qualitative Disclosures about Market Risk	39

Item 4.	Controls and Procedures	39

PART II.	OTHER INFORMATION	39

Item 1.	Legal Proceedings	39

Item 1A.	Risk Factors	40

Item 2.	Unregistered Sales of Equity Securities and Use of Proceeds	40

Item 3.	Defaults Upon Senior Securities	40

Item 4.	Mine Safety Disclosures	40

Item 5.	Other Information	40

Item 6.	Exhibits	41

Table of Contents

PART I. FINANCIAL INFORMATION

Item 1. Condensed Consolidated Financial Statements

TRINITY PLACE HOLDINGS INC.

CONSOLIDATED BALANCE SHEETS

(In thousands, except par value and share amounts)


	March 31,		December 31,
	2021		2020
	(unaudited)		(audited)
ASSETS

Real estate, net	$	289,294	$	279,204
Cash and cash equivalents		5,034		6,515
Restricted cash		6,694		9,554
Prepaid expenses and other assets, net		3,343		2,703
Investments in unconsolidated joint ventures		18,814		19,379
Receivables		919		966
Deferred rents receivable		102		90
Right-of-use asset		1,478		1,565
Intangible assets, net		8,987		9,172
Total assets	$	334,665	$	329,148

LIABILITIES

Loans payable, net	$	207,317	$	197,330
Corporate credit facility, net		32,104		31,858
Secured line of credit, net		8,950		7,747
Note payable		5,863		5,863
Accounts payable and accrued expenses		14,368		15,896
Lease liability		1,626		1,716
Warrant liability		3,196		830
Total liabilities		273,424		261,240

Commitments and Contingencies

STOCKHOLDERS’ EQUITY

Preferred stock, $0.01 par value; 40,000,000 shares authorized; no shares issued and outstanding		—		—
Preferred stock, $0.01 par value; 2 shares authorized; no shares issued and outstanding at March 31, 2021 and December 31, 2020		—		—
Special stock, $0.01 par value; 1 share authorized, issued and outstanding at March 31, 2021 and December 31, 2020		—		—
Common stock, $0.01 par value; 79,999,997 shares authorized; 38,840,508 and 38,345,540 shares issued at March 31, 2021 and December 31, 2020, respectively; 32,442,633 and 32,172,107 shares outstanding at March 31, 2021 and December 31, 2020, respectively		388		383
Additional paid-in capital		136,151		135,978
Treasury stock (6,397,875 and 6,173,433 shares at March 31, 2021 and December 31, 2020, respectively)		(57,166)		(56,791)
Accumulated other comprehensive loss		(2,040)		(2,159)
Accumulated deficit		(16,092)		(9,503)

Total stockholders’ equity		61,241		67,908

Total liabilities and stockholders’ equity	$	334,665	$	329,148

See Notes to Consolidated Financial Statements

Table of Contents

TRINITY PLACE HOLDINGS INC.

CONSOLIDATED STATEMENTS OF OPERATIONS AND COMPREHENSIVE LOSS

(In thousands, except per share amounts)


	Three Months Ended		Three Months Ended
	March 31,		March 31,
	2021		2020
	(unaudited)		(unaudited)
Revenues
Rental revenues	$	299	$	327
Other income		46		—
Total revenues		345		327

Operating Expenses
Property operating expenses		1,654		1,593
Real estate taxes		20		20
General and administrative		1,203		1,334
Pension related costs		163		165
Transaction related costs		1		15
Depreciation and amortization		715		601

Total operating expenses		3,756		3,728

Operating loss		(3,411)		(3,401)

Equity in net loss from unconsolidated joint ventures		(372)		(991)
Unrealized (loss) gain on warrants		(1,977)		1,200
Interest (expense) income, net		(601)		4
Interest expense - amortization of deferred finance costs		(193)		—

Loss before taxes		(6,554)		(3,188)

Tax expense		(35)		(65)

Net loss attributable to common stockholders	$	(6,589)	$	(3,253)

Other comprehensive gain:

Unrealized gain on pension liability		119		112
Comprehensive loss attributable to common stockholders	$	(6,470)	$	(3,141)

Loss per share - basic and diluted	$	(0.20)	$	(0.10)

Weighted average number of common shares - basic and diluted		32,591		32,268

See Notes to Consolidated Financial Statements

Table of Contents

TRINITY PLACE HOLDINGS INC.

CONSOLIDATED STATEMENTS OF STOCKHOLDERS’ EQUITY

FOR THE THREE MONTHS ENDED MARCH 31, 2021 AND 2020

(In thousands)



											Accumulated
				Additional							Other
	Common Stock			Paid-In		Treasury Stock			Accumulated		Comprehensive
	Shares	Amount		Capital		Shares	Amount		Deficit		Loss		Total
Balance as of December 31, 2019 (audited)	37,612	$	376	$	134,217	(5,731)	$	(55,731)	$	(15,997)	$	(3,174)	$	59,691

Net loss attributable to common stockholders	—		—		—	—		—		(3,253)		—		(3,253)
Settlement of stock awards	438		4		—	(197)		(648)		—		—		(644)
Unrealized gain on pension liability	—		—		—	—		—		—		112		112
Stock-based compensation expense	—		—		280	—		—		—		—		280
Stock-based consulting fees	190		2		598	—		—		—		—		600
Stock buy-back	—		—		—	(74)		(134)		—		—		(134)
Balance as of March 31, 2020 (unaudited)	38,240	$	382	$	135,095	(6,002)	$	(56,513)	$	(19,250)	$	(3,062)	$	56,652

Balance as of December 31, 2020 (audited)	38,345	$	383	$	135,978	(6,173)	$	(56,791)	$	(9,503)	$	(2,159)	$	67,908

Net loss attributable to common stockholders	—		—		—	—		—		(6,589)		—		(6,589)
Settlement of stock awards	496		5		—	(225)		(375)		—		—		(370)
Unrealized gain on pension liability	—		—		—	—		—		—		119		119
Stock-based compensation expense	—		—		173	—		—		—		—		173
Balance as of March 31, 2021 (unaudited)	38,841	$	388	$	136,151	(6,398)	$	(57,166)	$	(16,092)	$	(2,040)	$	61,241

See Notes to Consolidated Financial Statements

Table of Contents

TRINITY PLACE HOLDINGS INC.

CONSOLIDATED STATEMENTS OF CASH FLOWS

(In thousands)


	Three Months Ended		Three Months Ended
	March 31,		March 31,
	2021		2020
	(unaudited)		(unaudited)
CASH FLOWS FROM OPERATING ACTIVITIES:
Net loss attributable to common stockholders	$	(6,589)	$	(3,253)
Adjustments to reconcile net loss attributable to common stockholders to net cash used in operating activities:
Depreciation and amortization and amortization of deferred finance costs		908		601
Stock-based compensation expense		133		194
Deferred rents receivable		(12)		(15)
Other non-cash adjustments - pension expense		119		112
Unrealized loss (gain) on warrants		1,977		(1,200)
Equity in net loss from unconsolidated joint ventures		372		991
Distribution from unconsolidated joint ventures		194		305
Decrease (increase) in operating assets:
Receivables		47		(5)
Prepaid expenses and other assets, net		(371)		324
Increase (decrease) in operating liabilities:
Accounts payable and accrued expenses		1,294		(2,378)
Pension liabilities		—		(109)
Net cash used in operating activities		(1,928)		(4,433)

CASH FLOWS FROM INVESTING ACTIVITIES:
Additions to real estate		(12,202)		(18,244)
Deferred real estate deposits of condominiums		—		3,508
Investments in unconsolidated joint ventures		—		(5,382)
Net cash used in investing activities		(12,202)		(20,118)

CASH FLOWS FROM FINANCING ACTIVITIES:
Proceeds from loans and corporate credit facility		8,980		47,925
Proceeds from secured line of credit		1,200		—
Payment of finance costs		(21)		(77)
Repayment of loan		—		(15,368)
Settlement of stock awards		(370)		(644)
Stock buy-back		—		(134)
Net cash provided by financing activities		9,789		31,702

NET (DECREASE) INCREASE IN CASH AND CASH EQUIVALENTS AND RESTRICTED CASH		(4,341)		7,151
CASH AND CASH EQUIVALENTS AND RESTRICTED CASH, BEGINNING OF PERIOD		16,069		18,670
CASH AND CASH EQUIVALENTS AND RESTRICTED CASH, END OF PERIOD	$	11,728	$	25,821

CASH AND CASH EQUIVALENTS, BEGINNING PERIOD	$	6,515	$	9,196
RESTRICTED CASH, BEGINNING OF PERIOD		9,554		9,474
CASH AND CASH EQUIVALENTS AND RESTRICTED CASH, BEGINNING OF PERIOD	$	16,069	$	18,670

CASH AND CASH EQUIVALENTS, END OF PERIOD	$	5,034	$	11,192
RESTRICTED CASH, END OF PERIOD		6,694		14,629
CASH AND CASH EQUIVALENTS AND RESTRICTED CASH, END OF PERIOD	$	11,728	$	25,821

SUPPLEMENTAL DISCLOSURE OF CASH FLOW INFORMATION:
Cash paid during the period for: Interest	$	4,130	$	3,813
Cash paid during the period for: Taxes	$	46	$	63

SUPPLEMENTAL DISCLOSURE OF NON-CASH INVESTING AND FINANCING ACTIVITIES:
Accrued development costs included in accounts payable and accrued expenses	$	7,496	$	8,905
Capitalized amortization of deferred financing costs and warrants	$	760	$	968
Capitalized stock-based compensation expense	$	39	$	86
Investment in unconsolidated joint venture	$	—	$	5,193

See Notes to Consolidated Financial Statements

Table of Contents

Trinity Place Holdings Inc.
Notes to Condensed Consolidated Financial Statements (unaudited)
March 31, 2021

Note 1 – Business

Overview

Trinity Place Holdings Inc., which we refer to in this report as “Trinity,” “we,” “our,” or “us”, is a real estate holding, investment, development and asset management company. Our largest asset is currently a property located at 77 Greenwich Street in Lower Manhattan (“77 Greenwich”). 77 Greenwich was previously a vacant building that we demolished. It is under development as a mixed-use project consisting of a 90-unit residential condominium tower, retail space and a New York City elementary school. We also own a recently built 105-unit, 12-story multi-family property located at 237 11^th Street in Brooklyn, New York (“237 11^th”), acquired in May 2018, and, through joint ventures, a 50% interest in a recently built 95-unit multi-family property known as The Berkley, located at 223 North 8^th Street, Brooklyn (“The Berkley”) and a 10% interest in a recently built 234-unit multi-family property located one block from The Berkley at 250 North 10^th Street (“250 North 10^th”) acquired in January 2020, also in Brooklyn, New York. In addition, we own a property occupied by retail tenants in Paramus, New Jersey. Any references to square footage, property count or occupancy percentages, and any amounts derived from these values in these notes to the condensed consolidated financial statements, are outside the scope of our independent registered public accounting firm’s review.

We also control a variety of intellectual property assets focused on the consumer sector, a legacy of our predecessor, Syms Corp. (“Syms”), including FilenesBasement.com, our rights to the Stanley Blacker® brand, as well as the intellectual property associated with the Running of the Brides® event and An Educated Consumer is Our Best Customer® slogan. In addition, we had approximately $236.3 million of federal net operating loss carryforwards (“NOLs”) at March 31, 2021, which can be used to reduce our future taxable income and capital gains.

COVID-19 Pandemic, Liquidity and Going Concern

As a result of the COVID-19 pandemic which reached the USA in early 2020, numerous federal, state, local and foreign governmental authorities issued a range of “stay-at-home orders”, proclamations and directives aimed at minimizing the spread of COVID-19, among other restrictions on businesses and individuals. Additional proclamations and directives have been issued in response to further outbreaks, and may be issued in the future. The outbreak and restrictions have adversely affected our business operations including, among other things, a temporary suspension of construction work at our most significant asset, 77 Greenwich, which resumed in mid-April 2020, initially on a modified basis as certain work was deemed “essential” construction, and the temporary closing of the sales center for the 77 Greenwich residential condominium units as well as the temporary suspension of the remediation and restoration work being performed on 237 11^th, which resumed in early June 2020.

The economic downturn and volatility in financial markets appear to have been primarily driven by uncertainties associated with the pandemic. As it relates to our business, these uncertainties include, but are not limited to, the adverse effect of the pandemic on the New York City and broader economy, residential and potential residential sentiment in New York City, particularly Manhattan, lending institutions, construction and material supply partners, travel and transportation services, our employees, residents and tenants, and traffic to and within geographic areas containing our real estate assets. The pandemic has adversely affected our near-term, and may adversely affect our long-term, liquidity, cash flows and revenues and has required and may continue to require significant actions in response, including, but not limited to, reducing or discounting prices for our residential condominium units more than originally budgeted, seeking loan extensions and covenant modifications, modifying, eliminating or deferring rent payments in the short term for tenants in an effort to mitigate financial hardships and seeking access to federal, state and/or local financing and other programs. In addition, we continue to be subject to a New York State mandate disallowing tenant evictions for non-payment of rent due to COVID-19 related hardships.

The ultimate impact of the COVID-19 pandemic on our operations is unknown and will depend on future developments, which are highly uncertain and cannot be predicted with confidence, including the duration and severity of the outbreak, recurring outbreaks, new information which may emerge concerning the pandemic and any additional preventative and protective actions that governments, lending institutions and other businesses, including us, may direct or institute. These and other developments have resulted in and are expected to result in an extended period of continued business disruption

Table of Contents

and reduced operations for us as well as for lending and other businesses and governmental entities with which we do business. The ultimate financial impacts cannot be reasonably estimated at this time but the outbreak, restrictions and future developments are anticipated to continue to have an adverse impact on our business, financial condition and results of operations, which has been and may continue to be material, although in recent months we have seen indications of a recovery in the New York City real estate market and improvements in the financing markets.

The measures taken to date, together with any additional measures and developments including those noted above, impacted and will continue to impact the Company’s business in 2021 and beyond, although the extent of the significance of the impact of the COVID-19 outbreak on our business and the duration for which it may have an impact cannot be determined at this time.

Our financial statements are prepared using accounting principles generally accepted in the United States of America applicable to a going concern, which contemplate the realization of assets and liquidation of liabilities in the normal course of business. Given the impacts of COVID-19, it is possible that we may be unable to extend or refinance maturing debt, including the 237 11^th Loan (as defined in Note 5 - Loans Payable and Secured Line of Credit) which matures in June 2021, or meet future sales pace covenants under the amended 77 Greenwich Construction Facility (as defined in Note 5 - Loans Payable and Secured Line of Credit) which matures in January 2022, creating substantial doubt about our ability to continue as a going concern. Management’s plans to address the upcoming maturities consist of refinancings, including potentially an inventory loan at 77 Greenwich, and/or seeking an amendment or extension of either or both of such facilities. Although there is no assurance we will be able to refinance the facilities on terms acceptable to us, based on discussions with mortgage brokers and lenders, there is significant increased interest to date in 2021, as compared with 2020. Additionally, although the impact of the pandemic has impeded the sale of residential condominium units at 77 Greenwich, the pace of signing contracts has increased in 2021. The financial statements do not include any adjustments that might result from the outcome of any uncertainty as to our ability to continue as a going concern.

Note 2 – Summary of Significant Accounting Policies

Basis of Presentation

The accompanying unaudited consolidated financial statements were prepared in accordance with accounting principles generally accepted in the United States of America (“GAAP”) and include our financial statements and the financial statements of our wholly-owned subsidiaries.

The accompanying unaudited consolidated interim financial information also conform with the rules and regulations of the Securities and Exchange Commission (the “SEC”). Certain information and footnote disclosures normally included in annual financial statements prepared in accordance with GAAP have been condensed or omitted in accordance with such rules and regulations. Management believes that the disclosures presented in these unaudited consolidated financial statements are adequate to make the information presented not misleading. In management’s opinion, all adjustments and eliminations, consisting only of normal recurring adjustments, necessary to present fairly the financial position and results of operations for the reported periods have been included. The results of operations for such interim periods are not necessarily indicative of the results for the full year. The accompanying unaudited consolidated interim financial information should be read in conjunction with our December 31, 2020 audited consolidated financial statements, as previously filed with the SEC in our 2020 Annual Report on Form 10-K (the “2020 Annual Report”).

a. Principles of Consolidation - The consolidated financial statements include our accounts and those of our subsidiaries which are wholly-owned or controlled by us. Entities which we do not control through our voting interest and entities which are variable interest entities, but where we are not the primary beneficiary, are accounted for under the equity method. Accordingly, our share of the earnings or losses of our unconsolidated joint ventures, The Berkley and 250 North 10^th, are included in our consolidated statements of operations and comprehensive loss (see Note 12 – Investments in Unconsolidated Joint Ventures for further information). All significant intercompany balances and transactions have been eliminated.

We are required to consolidate a variable interest entity (the “VIE”) in which we are considered the primary beneficiary. The primary beneficiary is the entity that has (i) the power to direct the activities that most significantly impact the entity’s economic performance and (ii) the obligation to absorb losses of the VIE or the right to receive benefits from the VIE that could be significant to the VIE. As of March 31, 2021, 250 North 10^th

Table of Contents

was determined to be a VIE. Due to our lack of control and no equity at risk, we determined that we are not the primary beneficiary and we account for this investment under the equity method.

We assess the accounting treatment for joint venture investments, which includes a review of the joint venture or limited liability company agreement to determine which party has what rights and whether those rights are protective or participating. For potential VIEs, we review such agreements in order to determine which party has the power to direct the activities that most significantly impact the entity’s economic performance. In situations where we and our partner equally share authority, we do not consolidate the joint venture as we consider these to be substantive participation rights that result in shared power of the activities that most significantly impact the performance of the joint venture. Our joint venture agreements may contain certain protective rights such as requiring partner approval to sell, finance or refinance the property and the payment of capital expenditures and operating expenditures outside of the approved budget or operating plan.

Investments in Unconsolidated Joint Ventures - We account for our investments in unconsolidated joint ventures, namely, The Berkley and 250 North 10^th, under the equity method of accounting (see Note 12 - Investments in Unconsolidated Joint Ventures for further information). We also assess our investments in our unconsolidated joint ventures for recoverability, and if it is determined that a loss in value of an investment is other than temporary, we write down the investment to its fair value. We evaluate each equity investment for impairment based on each joint ventures' projected cash flows. We do not believe that the value of our equity investments was impaired at either March 31, 2021 or December 31, 2020.

c. Use of Estimates - The preparation of financial statements in conformity with GAAP requires management to make estimates and assumptions that affect the reported amounts of assets and liabilities and disclosure of contingent assets and liabilities at the date of the financial statements and the reported amounts of revenues and expenses during the reporting period. Accordingly, actual results could differ from those estimates.

d. Reportable Segments - We operate in one reportable segment, commercial real estate.

e. Concentrations of Credit Risk - Our financial instruments that are exposed to concentrations of credit risk consist primarily of cash and cash equivalents. We hold substantially all of our cash and cash equivalents in banks. Such cash balances at times exceed federally insured limits.

f. Real Estate - Real estate assets are stated at historical cost, less accumulated depreciation and amortization. All costs related to the improvement or replacement of real estate properties are capitalized. Additions, renovations and improvements that enhance and/or extend the useful life of a property are also capitalized. Expenditures for ordinary maintenance, repairs and improvements that do not materially prolong the useful life of an asset are charged to operations as incurred. Depreciation and amortization are determined using the straight-line method over the estimated useful lives as described in the table below:


Category		Terms
Buildings and improvements		10 - 39 years
Tenant improvements		Shorter of remaining term of the lease or useful life
Furniture and fixtures		5 - 8 years

Real Estate Under Development - We capitalize certain costs related to the development and redevelopment of real estate including initial project acquisition costs, pre-construction costs and construction costs for each specific property. Additionally, we capitalize operating costs, interest, real estate taxes, insurance and compensation and related costs of personnel directly involved with the specific project related to real estate under development. Capitalization of these costs begin when the activities and related expenditures commence, and ceases when the property is held available for occupancy upon substantial completion of tenant improvements, but no later than one year from the completion of major construction activity at which time the project is placed in service and depreciation commences. Revenue earned under short-term license agreements at properties under development is offset against these capitalized costs.

Valuation of Long-Lived Assets - We periodically review long-lived assets for impairment whenever changes in circumstances indicate that the carrying amount of the assets may not be fully recoverable. We consider relevant cash flow, management’s strategic plans and significant decreases, if any, in the market value of the asset and other available information in assessing whether the carrying value of the assets can be recovered. When such

Table of Contents

events occur, we compare the carrying amount of the asset to the undiscounted expected future cash flows, excluding interest charges, from the use and eventual disposition of the asset. If this comparison indicates an impairment, the carrying amount would then be compared to the estimated fair value of the long-lived asset. An impairment loss would be measured as the amount by which the carrying value of the long-lived asset exceeds its estimated fair value. 77 Greenwich is a residential condominium development project currently in the development stage and forecasting the expected future cash flows requires management to make significant assumptions and estimates in relation to the remaining costs to complete the project, potential delays or disruptions in construction due to COVID-19 restrictions, and potential sales proceeds to be received upon sale of residential condominium units in light of market disruptions due to the COVID-19 pandemic. We also identified the existence of an impairment evaluation triggering event in relation to our 237 11^th Street property as a result of property damage caused by certain construction defects in place prior to acquisition. Significant judgments and estimates are required by management in determining the asset’s estimated future cash flows, including future revenue and operating expense growth rates, holding period, estimated terminal value, estimated costs to sell, and other market-based assumptions. We considered all the aforementioned indicators of impairment for the three months ended March 31, 2021 and 2020, respectively. No provision for impairment was recorded during the three months ended March 31, 2021 or 2020, respectively.

Fair Value Measurements - We determine fair value in accordance with Accounting Standards Codification (“ASC”) 820, “Fair Value Measurement,” for financial assets and liabilities. This standard defines fair value, provides guidance for measuring fair value and requires certain disclosures.

Fair value is defined as the price that would be received to sell an asset or transfer a liability in an orderly transaction between market participants at the measurement date. Where available, fair value is based on observable market prices or parameters or derived from such prices or parameters. Where observable prices or inputs are not available, valuation models are applied. These valuation techniques involve some level of management estimation and judgment, the degree of which is dependent on the price transparency for the instruments or market and the instruments’ complexity. Assets and liabilities disclosed at fair value are categorized based upon the level of judgment associated with the inputs used to measure their fair value. Hierarchical levels, which are defined by ASC 820-10-35, are directly related to the amount of subjectivity associated with the inputs to the fair valuation of these assets and liabilities. Determining which category an asset or liability falls within the hierarchy requires significant judgment and we evaluate our hierarchy disclosures each quarter.

Level 1 - Valuations based on quoted prices for identical assets and liabilities in active markets.

Level 2 - Valuations based on observable inputs other than quoted prices included in Level 1, such as quoted prices for similar assets and liabilities in active markets, quoted prices for identical or similar assets and liabilities in markets that are not active, or other inputs that are observable or can be corroborated by observable market data.

Level 3 - Valuations based on unobservable inputs reflecting management’s own assumptions, consistent with reasonably available assumptions made by other market participants. These valuations require significant judgment.

j. Cash and Cash Equivalents - Cash and cash equivalents include securities with original maturities of three months or less when purchased.

k. Restricted Cash - Restricted cash represents amounts required to be restricted under our loan agreements, letters of credit (see Note 5 - Loans Payable and Secured Line of Credit for further information), deposits on condominium sales at 77 Greenwich and tenant related security deposits.

Revenue Recognition - Leases with tenants are accounted for as operating leases. Minimum rents are recognized on a straight-line basis over the term of the respective lease, beginning when the tenant takes possession of the space. The excess of rents recognized over amounts contractually due pursuant to the underlying leases are included in deferred rents receivable. In addition, retail leases typically provide for the reimbursement of real estate taxes, insurance and other property operating expenses. As lessor, when reporting revenue, we have elected to combine the lease and non-lease components of our operating lease agreements and account for the components as a single lease component in accordance with ASC Topic 842. Lease revenues and reimbursement of real estate

Table of Contents

taxes, insurance and other property operating expenses are presented in the consolidated statements of operations and comprehensive loss as “rental revenues.” Also, these reimbursements of expenses are recognized within revenue in the period the expenses are incurred. We assess the collectability of our accounts receivable related to tenant revenues. With the adoption of ASC Topic 842, we applied the guidance under ASC 842 in assessing its lease payments: if collection of rents under specific operating leases is not probable, then we recognize the lesser of that lease’s rental income on a straight-line basis or cash received, plus variable rents as earned. Once this assessment is completed, we apply a general reserve, as provided under ASC 450-20, if applicable. Also, we have elected the ‘package or practical expedients’ approach which allows us not to reassess our previous conclusions about lease identification, lease classification and initial direct costs.

Stock-Based Compensation – We have granted stock-based compensation, which is described below in Note 11 – Stock-Based Compensation. We account for stock-based compensation in accordance with ASC 718, “Compensation-Stock Compensation,” which establishes accounting for stock-based awards exchanged for employee services and ASU No. 2018-07, “Compensation - Stock Compensation (Topic 718), Improvements to Nonemployee Share-Based Payment Accounting,” which provides additional guidance related to share-based payment transactions for acquiring goods or services from nonemployees. Under the provisions of ASC 718-10-35, stock-based compensation cost is measured at the grant date, based on the fair value of the award on that date, and is expensed at the grant date (for the portion that vests immediately) or ratably over the related vesting periods.

Income Taxes - We account for income taxes under the asset and liability method as required by the provisions of ASC 740, “Income Taxes.” Under this method, deferred tax assets and liabilities are determined based on differences between financial reporting and tax bases of assets and liabilities and are measured using the enacted tax rates and laws that will be in effect when the differences are expected to reverse. We provide a valuation allowance for deferred tax assets for which we do not consider realization of such assets to be more likely than not.

ASC 740-10-65 addresses the determination of whether tax benefits claimed or expected to be claimed on a tax return should be recorded in the financial statements. Under ASC 740-10-65, we may recognize the tax benefit from an uncertain tax position only if it is more likely than not that the tax position will be sustained on examination by the taxing authorities based on the technical merits of the position. The tax benefits recognized in the financial statements from such a position should be measured based on the largest benefit that has a greater than fifty percent likelihood of being realized upon ultimate settlement. ASC 740-10-65 also provides guidance on de-recognition, classification, interest and penalties on income taxes, accounting in interim periods and increased other disclosures. As of March 31, 2021 and December 31, 2020, we had determined that no liabilities are required in connection with unrecognized tax positions. As of March 31, 2021, our tax returns for the years ended December 31, 2017 through December 31, 2020 are subject to review by the Internal Revenue Service. Our state returns are open to examination for the years December 31, 2016 or 2017 through December 31, 2020, depending on the jurisdiction.

We are subject to certain federal, state and local income and franchise taxes.

o. Earnings (loss) Per Share - We present both basic and diluted earnings (loss) per share. Basic earnings (loss) per share is computed by dividing net income (loss) attributable to common stockholders by the weighted average number of shares of common stock outstanding for the period. Diluted earnings (loss) per share reflects the potential dilution that could occur if securities or other contracts to issue common stock were exercised or converted into common stock, where such exercise or conversion would result in a lower per share amount. Shares issuable comprising 290,074 restricted stock units that have vested but not yet settled and 7,179,000 warrants exercisable at $4.50 per share were excluded from the computation of diluted loss per share because the awards would have been antidilutive for the three months ended March 31, 2021 and 2020.

p. Deferred Finance Costs – Capitalized and deferred finance costs represent commitment fees, legal, title and other third party costs associated with obtaining commitments for mortgage financings which result in a closing of such financing. These costs are being offset against loans payable and secured line of credit in the consolidated balance sheets for mortgage financings and had a balance of $1.6 million and $2.6 million at March 31, 2021 and December 31, 2020, respectively. Costs for our corporate credit facility are being offset against corporate credit facility, net in the consolidated balance sheets and had a balance of $3.6 million and $3.9 million at March 31, 2021 and December 31, 2020, respectively. Deferred finance costs are amortized over the terms of the related

Table of Contents

financing arrangements. Unamortized deferred finance costs are expensed when the associated debt is refinanced or repaid before maturity. Costs incurred in seeking financing transactions which do not close are expensed in the period in which it is determined that the financing will not close.

q. Deferred Lease Costs – Deferred lease costs consist of fees and direct costs incurred to initiate and renew retail operating leases and are amortized to depreciation and amortization on a straight-line basis over the related non-cancelable lease term. Lease costs incurred under our residential leases are expensed as incurred.

r. Underwriting Commissions and Costs – Underwriting commissions and costs incurred in connection with our stock offerings are reflected as a reduction of additional paid-in-capital in stockholders’ equity.

Accounting Standards Updates

Recently Adopted Accounting and Reporting Guidance

In December 2019, the Financial Accounting Standards Board (the “FASB”) issued Account Standards Update (“ASU”) 2019-12, Income Taxes (Topic 740) Simplifying the Accounting for Income Taxes. The amendments in this ASU provide guidance for interim period and intra period tax accounting; provide tax accounting guidance for foreign subsidiaries; require that an entity recognize a franchise (or similar) tax that is partially based on income as an income-based tax and account for any incremental amount incurred as a non-income-based tax; as well as other changes to tax accounting. This ASU is effective for fiscal years beginning after December 15, 2020. The Company usually does not have significant income taxes. Accordingly, the implementation of this guidance did not have a material effect on our financial position, results of operations or cash flows.

In January 2020, the FASB issued ASU 2020-01 Investments—Equity securities (Topic 321), Investments—Equity Method and Joint Ventures (Topic 323), and Derivatives and Hedging (Topic 815)—Clarifying the Interactions Between Topic 321, Topic 323, and Topic 815. The amendments in this ASU affect all entities that apply the guidance in Topics 321, 323, and 815 and (i) elect to apply the measurement alternative or (ii) enter into a forward contract or purchase an option to purchase securities that, upon settlement of the forward contract or exercise of the purchased option, would be accounted for under the equity method of accounting. This ASU is effective for fiscal years beginning after December 15, 2020. Currently, we do not apply the measurement alternative and we do not have any such forward contracts or purchase options. As a result, the implementation of this guidance did not have any effect on our financial position, results of operations or cash flows.

Recently Issued Accounting Pronouncements

In January 2021, the FASB issued ASU 2021-01 Reference Rate Reform (Topic 848) which modifies ASC 848 (ASU 2020-04 discussed above), which was intended to provide relief related to “contracts and transactions that reference LIBOR or a reference rate that is expected to be discontinued as a result of reference rate reform.” ASU 2021-01 expands the scope of ASC 848 to include all affected derivatives and give reporting entities the ability to apply certain aspects of the contract modification and hedge accounting expedients to derivative contracts affected by the discounting transition. ASU 2021-01 also adds implementation guidance to clarify which optional expedients in ASC 848 may be applied to derivative instruments that do not reference LIBOR or a reference rate that is expected to be discontinued, but that are being modified as a result of the discounting transition. Currently, we do not have any trades cleared by a central counterparty. As a result, the implementation of this guidance is not expected to have any effect on our financial position, results of operations or cash flows.

Table of Contents

Note 3 – Real Estate, Net

As of March 31, 2021 and December 31, 2020, real estate, net, includes the following (in thousands):


	March 31,		December 31,
	2021		2020

Real estate under development	$	223,670	$	213,178
Building and building improvements		41,358		41,358
Tenant improvements		189		189
Furniture and fixtures		734		731
Land and land improvements		27,939		27,939
		293,890		283,395
Less: accumulated depreciation		4,596		4,191
	$	289,294	$	279,204

Real estate under development as of March 31, 2021 and December 31, 2020 included 77 Greenwich and the Paramus, New Jersey property. Building and building improvements, tenant improvements, furniture and fixtures, and land and land improvements included the 237 11^th property as of March 31, 2021 and December 31, 2020.

Depreciation expense amounted to approximately $408,000 and $403,000 for the three months ended March 31, 2021 and 2020, respectively.

77 Greenwich and the New York City School Construction Authority

We entered into an agreement with the SCA, whereby we agreed to construct a school to be sold to the SCA as part of our condominium development at 77 Greenwich. Pursuant to the agreement, the SCA agreed to pay us $41.5 million for the purchase of their condominium unit and reimburse us for the costs associated with constructing the school, including a construction supervision fee of approximately $5.0 million. Payments for construction are being made by the SCA to the general contractor in installments as construction on their condominium unit progresses. Payments to us for the land and construction supervision fee commenced in January 2018 and continued through October 2019 for the land and will continue through the second quarter of 2021 for the construction supervision fee, with an aggregate of $46.0 million having been paid to us as of March 31, 2021 from the SCA, with $333,000 remaining to be paid. We have also received an aggregate of $49.3 million in reimbursable construction costs from the SCA through March 31, 2021. The payments and reimbursements from the SCA received prior to April 2020 were recorded as deferred real estate deposits on the consolidated balance sheets until sales criteria were satisfied in April 2020. In April 2020, the SCA closed on the purchase of the school condominium unit with us, at which point title transferred to the SCA, and the SCA is now proceeding to complete the buildout of the interior space, which is planned to become an approximately 476 seat public elementary school. Upon conveyance, we recognized a gain on the sale of approximately $20.0 million and an additional gain of $4.2 million related to the recognition of our deferred construction supervision fee, and our liquidity requirement on the 77 Greenwich Construction Facility decreased from $15.0 million to $10.0 million. We have also guaranteed certain obligations with respect to the construction of the school.

237 11^th

In May 2018, we closed on the acquisition of 237 11^th, a recently built 105-unit, 12-story multi-family apartment building located at 237 11^thStreet, Brooklyn, New York for a purchase price of $81.2 million, excluding transaction costs of approximately $0.7 million. The acquisition was funded through acquisition financing and cash on hand. Due to certain construction defects at 237 11^th that resulted in water penetration into the building and damage to certain apartment units and other property, which defects we believe were concealed and which would have required significant invasive work of a type not usually required or permitted, especially on a newly-built asset, to be detected, we submitted proofs of loss to our insurance carrier for property damage and business interruption (lost revenue) in March 2019. The insurance carrier subsequently disclaimed coverage for the losses and we filed a complaint against the carrier and its administrator, alleging that they breached the insurance policy by denying coverage and requesting a declaration that they are obligated to cover the claimed damage. We also filed legal claims against the seller, its parent company, and the general contractor to recover damages arising from the defective construction. In addition, the general contractor impleaded into that litigation several subcontractors who performed work on the property. Management expects to recover some portion of the cost incurred to

Table of Contents

repair the property through the litigations and/or settlement negotiations with the seller, its parent company, the general contractor, the subcontractors, and the insurance carrier, although the amount of damages that may be recoverable in litigation and/or potential settlement negotiations are uncertain at this time, as is the receipt of any such payments, which has been impacted by the COVID-19 pandemic, including the resulting backlog in the court system and slowdown in judicial proceedings. We have been in discussions with the seller, its parent company, the general contractor, and the third-party defendants impleaded by the general contractor about engaging in mediation to potentially settle the case involving those parties. A mediation process commenced at the end of February 2021. We incurred significant cash outflows for costs associated with these repairs and remediation, which commenced in September 2019. As of April 30, 2021, the property was approximately 43% leased.

We allocated the purchase price of the real estate to land and land improvements, building and building improvements (inclusive of tenant improvements) and intangibles, such as the value of above-market and below-market leases, real estate tax abatements and origination costs associated with the in-place leases.

As of March 31, 2021 and December 31, 2020, intangible assets, net consisted of the real estate tax abatement at its original valuation of $11.1 million offset by its related accumulated amortization of approximately $2.1 million and $1.9 million at March 31, 2021 and December 31, 2020, respectively. Amortization expense amounted to $185,000 for the three months ended March 31, 2021 and 2020, respectively.

Note 4 – Prepaid Expenses and Other Assets, Net

As of March 31, 2021 and December 31, 2020, prepaid expenses and other assets, net, include the following (in thousands):


	March 31,		December 31,
	2021		2020

Prepaid expenses		794		454
Deferred finance costs		2,184		1,795
Other		1,449		954
		4,427		3,203
Less: accumulated amortization		1,084		500
	$	3,343	$	2,703

Note 5 – Loans Payable and Secured Line of Credit

Corporate Credit Facility

In December 2019, we entered into a multiple draw credit agreement aggregating $70.0 million (the “Corporate Credit Facility”), which may be increased by $25.0 million subject to satisfaction of certain conditions and the consent of the lender (the “CCF Lender”). Draws under the Corporate Credit Facility may be made during the 32-month period following the closing date of the Corporate Credit Facility (the “Closing Date”). The Corporate Credit Facility matures on December 19, 2024, subject to extensions until December 19, 2025 and June 19, 2026, respectively, under certain circumstances. The proceeds of the Corporate Credit Facility may be used for investments in certain multi-family apartment buildings in the greater New York City area and certain non-residential real estate investments approved by the CCF Lender in its reasonable discretion, as well as in connection with certain property recapitalizations and in specified amounts for general corporate purposes and working capital. The Corporate Credit Facility had an outstanding balance of $35.75 million at both March 31, 2021 and December 31, 2020, excluding deferred finance fees of $3.6 million and $3.9 million, respectively. Accrued interest totaled approximately $2.0 million and $1.5 million at March 31, 2021 and December 31, 2020, respectively. As of March 31, 2021, we were in compliance with all covenants of the Corporate Credit Facility.

The Corporate Credit Facility bears interest at a rate per annum equal to the sum of (i) 5.25% and (ii) a scheduled interest rate of 4% (the “Cash Pay Interest Rate”) which increases by 0.125% every six-month period from the Closing Date, subject to increase during the extension periods. The effective interest rate at March 31, 2021 and December 31, 2020 was 9.5%. A $2.45 million commitment fee was payable 50% on the initial draw and 50% as amounts under the Corporate Credit Facility are drawn, with any remaining balance due on the last date of the draw period, and a 1.0% exit fee is payable in respect of Corporate Credit Facility repayments. As of March 31, 2021, we had paid $1.85 million of the commitment fee. The Corporate Credit Facility may be prepaid at any time subject to a prepayment premium on the portion of the

Table of Contents

Corporate Credit Facility being repaid. The Corporate Credit Facility is subject to certain mandatory prepayment provisions, including that, subject to the terms of the mortgage loan documents applicable to the Company’s 77 Greenwich property, 90% or 100% of the net cash proceeds of residential condominium sales, depending on the circumstances, and 70% of the net cash proceeds of retail condominium sales at the Company’s 77 Greenwich property shall be used to repay the Corporate Credit Facility. Upon final repayment of the Corporate Credit Facility, a multiple on invested capital, or MOIC, amount equal to 130% of the initial Corporate Credit Facility amount plus drawn incremental amounts less the sum of all interest payments, commitment fee and exit fee payments and prepayment premiums, if any, shall be due, if such amounts together with the aggregate amount of principal repaid are less than the MOIC amount. The collateral for the Corporate Credit Facility consists of (i) 100% of the equity interests in our direct subsidiaries, to the extent such a pledge is permitted by the organizational documents of such subsidiary and any financing agreements to which such subsidiary is a party, (ii) our cash and cash equivalents, excluding restricted cash and cash applied toward certain liquidity requirements under existing financing arrangements, and (iii) other non-real estate assets of ours, including intellectual property.

The Corporate Credit Facility provides that we and our subsidiaries must comply with various affirmative and negative covenants including restrictions on debt, liens, business activities, equity repurchases, distributions and dividends, disposition of assets and transactions with affiliates, as well as financial covenants regarding corporate loan to value, net worth and liquidity. Under the Corporate Credit Facility, we are permitted to repurchase up to $2.0 million of our common stock pursuant to board approved programs with Corporate Credit Facility proceeds, $1.5 million with other sources of cash and otherwise subject to the consent of the required lenders. The Corporate Credit Facility also provides for certain events of default, including cross-defaults to our other loans, and for a guaranty of the Corporate Credit Facility obligations by our loan party subsidiaries.

Pursuant to the terms of the Corporate Credit Facility, so long as the Corporate Credit Facility is outstanding and the CCF Lender is owed or holds greater than 50% of the sum of (x) the aggregate principal amount of the balance outstanding and (y) the aggregate unused commitments, the CCF Lender will have the right to appoint one member to our and each of our subsidiary’s board of directors or equivalent governing body (the “Designee”). At the election of the CCF Lender, a board observer may be selected in lieu of a board member. The Designee may also sit on up to three committees of the board of directors or equivalent governing body of ours and each subsidiary of the Designee’s choosing from time to time. The Designee will be entitled to receive customary reimbursement of expenses incurred in connection with his or her service as a member of the board and/or any committee thereof but will not, except in the case of an independent director, receive compensation for such service.

In connection with the December 2020 transaction noted below, the Company entered into an amendment to the Corporate Credit Facility, pursuant to which, among other things, (i) we were permitted to enter into the Mezzanine Loan Agreement (as defined below), the amendment to the 77 Greenwich Construction Facility (as defined below) and related documents, (ii) the commitment made by the CCF Lender under the Corporate Credit Facility was reduced by $7.5 million, and (iii) the MOIC amount, was amended to combine the Corporate Credit Facility and the Mezzanine Loan. In addition, the exercise price of the warrants issued in connection with the Corporate Credit Facility was amended from $6.50 per share to $4.50 per share (the “Warrant Agreement Amendment”) (see Note 10 – Stockholders Equity – Warrants for further discussion regarding the warrants).

Loans Payable

237 11^thLoans

In May 2018, in connection with the acquisition of 237 11^th, we entered into two-year interest-only financings with an aggregate principal amount of $67.8 million, comprised of a $52.4 million mortgage loan (the “237 11^th Loan”) and a $15.4 million mezzanine loan bearing interest at a blended average rate of 3.72% over the 30-day LIBOR, each with a one-year extension option upon satisfaction of certain conditions. The mezzanine loan was repaid in full in February 2020. In June 2020, the maturity of the 237 11^th Loan was extended to June 2021 and the 237 11^th Loan was amended to include a delayed draw facility of $4.25 million, which is being drawn now that most of the $3.6 million of remediation reserves we funded in connection with the amendment have been used. As of March 31, 2021, $2.8 million of the delayed draw funds had been drawn. We also funded an interest reserve account of $0.8 million which we are required to replenish over time. In conjunction with the amendment, a LIBOR floor of 50 basis points was put in place, the spread was increased by 25 basis points to 2.25% and the exit fee was increased by 50 basis points to 1.0%. At March 31, 2021 and December 31, 2020, the 237 11^th Loan had a balance of $55.2 million and $53.2 million, respectively, and an effective interest rate of

Table of Contents

2.75%, respectively. The 237 11^th Loan is non-recourse to us except for environmental indemnity agreements, certain non-recourse carve-out and carry guaranties covering among other things interest and operating expenses, and in the case of the mortgage loan, a guaranty of 25% of the principal amount, decreasing to 10% of the principal balance upon the debt yield ratio becoming equal to or greater than 7.0%. The 237 11^th Loan is prepayable at any time in whole, and under certain circumstances in part, upon payment of a 0.50% deferred commitment fee (unless the loan is refinanced with the mortgage lender in which case no such fee is payable). We have signed a term sheet and expect to close, subject to normal closing conditions, on the refinancing of the acquisition loan prior to its maturity date.

The 237 11^th Loan requires us to comply with various customary affirmative and negative covenants and provides for certain events of default, the occurrence of which would permit the lender to declare the 237 11^th Loan due and payable, among other remedies. Effective December 31, 2020, the recourse guaranty for the 237 11^th Loan was amended to decrease certain liquidity requirements. As of March 31, 2021, we were in compliance with all covenants of the 237 11^th Loan.

77 Greenwich Construction Facility

In December 2017, we closed on a $189.5 million construction facility for 77 Greenwich (the “77 Greenwich Construction Facility”). We draw down proceeds as costs related to the construction of the new mixed-use building are incurred. The plans call for the development of 90 luxury residential condominium apartments, 7,500 square feet of retail space, almost all of which is street level, a 476-seat elementary school serving New York City District 2, including the adaptive reuse of the landmarked Robert and Anne Dickey House, and construction of a new handicapped accessible subway entrance on Trinity Place. There was an outstanding balance of approximately $145.9 million and $139.0 million on the 77 Greenwich Construction Facility at March 31, 2021 and December 31, 2020, respectively.

The 77 Greenwich Construction Facility has a four-year term ending January 2022 with an extension option for an additional year under certain circumstances. The collateral for the 77 Greenwich Construction Facility is the borrower’s fee interest in 77 Greenwich, which is the subject of a mortgage in favor of the 77 Greenwich Lender, as well as related collateral and a pledge of equity in the borrower. The 77 Greenwich Construction Facility bears interest on amounts drawn at a rate per annum equal to the greater of (i) LIBOR plus 8.25% and (ii) 9.25%. The effective interest rate at March 31, 2021 and December 31, 2020 was 9.25%, respectively. The 77 Greenwich Construction Facility provides for certain loan proceeds to be advanced as an interest holdback and to the extent that the cash flow from 77 Greenwich is insufficient to pay the interest payments then due and payable, funds in the interest holdback will be applied by the lender as a disbursement to the borrower to make the monthly interest payments on the 77 Greenwich Construction Facility, subject to certain conditions. The 77 Greenwich Construction Facility may be prepaid in part in certain circumstances such as in the event of the sale of residential and retail condominium units. Pursuant to the December 2020 amendment to the 77 Greenwich Construction Facility, we are required to achieve substantial completion of the construction work and the improvements for the project on or before November 30, 2021, subject to certain exceptions. As of April 30, 2021, in connection with a potential refinancing of this loan, we have received several indicative offers from lenders across the debt stack.

In connection with the 77 Greenwich Construction Facility, we executed certain guaranties and environmental indemnities, including a recourse guaranty under which we are required to satisfy certain net worth and liquidity requirements including the Company maintaining liquidity of at least $15.0 million, consisting of unrestricted cash and, for up to 50% of the requirement, qualified lines of credit, and additional customary affirmative and negative covenants for loans of this type and our agreements with the SCA. The liquidity requirement decreased to $10.0 million upon conveyance of the school condominium to the SCA in April 2020 and was further decreased to $8.0 million upon obtaining the first temporary certificate of occupancy (“TCO”). We also entered into certain completion and other guarantees with the lender and the SCA in connection with the 77 Greenwich Construction Facility. As of March 31, 2021, we were in compliance with all covenants of the 77 Greenwich Construction Facility.

In early April 2020, New York State required all non-essential construction projects be shut down due to the impact of the COVID-19 pandemic. As a result, the construction of 77 Greenwich was temporarily suspended. Construction recommenced mid-April, initially on a modified basis, as certain work was deemed "essential" construction. Since June 2020, a full crew has been on site and operating in accordance with applicable guidelines in response to the COVID-19 outbreak. Future delays in construction may result in a delay in our ability to complete the construction project on its original timeline and our ability to sell condominium units. We currently anticipate receiving our TCOs in stages throughout 2021, with the first TCO having been received on March 8, 2021.

Table of Contents

In December 2020, we entered into an amendment to the 77 Greenwich Construction Facility, pursuant to which, among other things, the sales pace covenants were amended and extended to provide for a reduction in the gross value of condominium sales at the 77 Greenwich and to afford more favorable cure rights than previously existed if a required sales threshold is not satisfied. We were in compliance with the April 1, 2021 sales pace covenant test and the sales pace covenant will be tested again on July 1, 2021 and October 2, 2021. Additionally, the outside date by which we are required to have substantially completed construction of all improvements to 77 Greenwich was extended to November 30, 2021 and the liquidity requirements will be reduced based on construction progress. We received our first TCO on March 8, 2021. Upon the granting of the TCO and our condominium offering plan being declared effective, unit purchasers may occupy their units. In connection with this amendment, we paid down $8.0 million of the 77 Greenwich Construction Facility and funded certain reserves to the lender, a portion of which was funded by a release of certain cash collateral and the balance of which was funded by a mezzanine loan (see below). Under the terms of this amendment, to the extent that any payments are needed to satisfy the minimum multiple fee owed to the mortgage lender upon the repayment of the 77 Greenwich Construction Facility that have not already been paid, such minimum multiple fee will be reduced by 60% if the 77 Greenwich Construction Facility is repaid in full prior to June 30, 2021, and by 40% if repaid between July 1, 2021 and September 30, 2021. The Company currently expects any such payments to be minimal (if anything).

In December 2017, we entered into an interest rate cap agreement as required under the 77 Greenwich Construction Facility. The interest rate cap agreement provided the right to receive cash if the reference interest rate rose above a contractual rate. We paid a premium of approximately $393,000 for the 2.5% interest rate cap on the 30-day LIBOR rate on a notional amount of $189.5 million. The interest rate cap matured in December 2020. We did not designate this interest rate cap as a hedge and are recognizing the change in estimated fair value in interest expense.

Mezzanine Loan

In December 2020, we entered into a mezzanine loan agreement with an affiliate of the CCF Lender (the “Mezzanine Loan Agreement”, and the loan thereunder, the “Mezzanine Loan”). The Mezzanine Loan is for an amount of $7.5 million and has a term of three years with two one-year extension options, exercisable under certain circumstances. The collateral for the Mezzanine Loan is the borrower’s equity interest in its direct, wholly-owned subsidiary, which owns 100% of the equity interests in the borrower under the 77 Greenwich Construction Facility. The blended interest rate for the 77 Greenwich Construction Facility and the Mezzanine Loan, assuming the 77 Greenwich Construction Facility and the Mezzanine Loan are fully drawn, is 9.44% on an annual basis, representing a variance from the prior rate of approximately 19 basis points. Interest on the Mezzanine Loan is not payable on a monthly basis but instead is automatically added to the unpaid principal amount on a monthly basis (and therefore accrues interest) and is payable in full on the maturity date of the Mezzanine Loan. Upon final repayment of the Mezzanine Loan, a MOIC shall be due on substantially the same terms as provided for in the Corporate Credit Facility. The Mezzanine Loan may not be prepaid prior to prepayment in full of the 77 Greenwich Construction Facility, but if the 77 Greenwich Construction Facility is being prepaid in full, the Mezzanine Loan may be prepaid simultaneously therewith. Subject to the prior sentence the Mezzanine Loan may be prepaid in whole or in part, without penalty or premium (other than payment of the MOIC amount, if applicable, as provided above), upon prior written notice to mezz lender. In connection with the Mezzanine Loan, the Company entered into a completion guaranty, carry guaranty, equity funding guaranty, recourse guaranty and environmental indemnification undertaking substantially consistent with the Company’s existing guarantees made to the 77 Greenwich Lender in connection with the 77 Greenwich Construction Facility.

Secured Line of Credit

Our $12.75 million secured line of credit is secured by the Paramus, New Jersey property. In March 2021, we entered into an amendment to extend the maturity date to March 2022. The secured line of credit, which prior to the amendment, bore interest at a rate of 200 basis points over the 30-day LIBOR, now bears interest at the prime rate, currently 3.25%. The secured line of credit is pre-payable at any time without penalty. This secured line of credit had an outstanding balance of $8.95 million and $7.75 million at March 31, 2021 and December 31, 2020, respectively, and an effective interest rate of 3.25% and 2.14% as of March 31, 2021 and December 31, 2020, respectively.

250 North 10^th Note

Table of Contents

of the equity totaling approximately $5.9 million was funded through a loan (the “Partner Loan”) from our joint venture partner. The Partner Loan had a balance of $5.9 million at March 31, 2021 and December 31, 2020, respectively, bears interest at 7.0% and is prepayable any time within its four year term. Our partner has the option of having the Partner Loan repaid in our common stock if the price of our common stock exceeds $6.50 per share at the time of conversion.

Interest

Consolidated interest expense (income), net includes the following (in thousands):


	Three Months Ended		Three Months Ended
	March 31,		March 31,
	2021		2020
Interest expense	$	4,988	$	3,970
Interest capitalized		(4,387)		(3,970)
Interest income		—		(4)
Interest expense (income), net	$	601	$	(4)

Note 6 – Fair Value Measurements

The fair value of our financial instruments are determined based upon applicable accounting guidance. Fair value is defined as the price that would be received to sell an asset or paid to transfer a liability in an orderly transaction between market participants at the measurement date. The guidance requires disclosure of the level within the fair value hierarchy in which the fair value measurements fall, including measurements using quoted prices in active markets for identical assets or liabilities (Level 1), quoted prices for similar instruments in active markets or quoted prices for identical or similar instruments in markets that are not active (Level 2), and significant valuation assumptions that are not readily observable in the market (Level 3).

The fair values of cash and cash equivalents, receivables, accounts payable and accrued expenses, and other liabilities approximated their carrying value because of their short-term nature. The fair value of the consolidated loans payable, Corporate Credit Facility, the secured line of credit and the note payable approximated their carrying values as they are variable-rate instruments. The warrant liability is recorded at fair value.

Note 7 – Pension Plans

Defined Benefit Pension Plan

Syms sponsored a defined benefit pension plan for certain eligible employees not covered under a collective bargaining agreement. The pension plan was frozen effective December 31, 2006. At March 31, 2021 and December 31, 2020, we had recorded an overfunded pension balance of $343,000, respectively, which is included in prepaid expenses and other assets, net on the accompanying consolidated balance sheets. If we decided to terminate the plan under a standard termination, we would be required to make additional contributions to the plan so that the assets of the plan are sufficient to satisfy all benefit liabilities.

We currently plan to continue to maintain the Syms pension plan and make all contributions required under applicable minimum funding rules; however, we may terminate it at any time. In the event we terminate the plan, we intend that any such termination would be a standard termination. Although we have accrued the liability associated with a standard termination, we have not taken any steps to commence such a termination and currently have no intention of terminating the pension plan. In accordance with minimum funding requirements and court ordered allowed claims distributions, we paid approximately $5.3 million to the Syms sponsored plan from September 17, 2012 through March 31, 2021. Historically, we have funded this plan in the third quarter of the calendar year. We funded $400,000 to the Syms sponsored plan during the year ended December 31, 2020.

Table of Contents

Note 8 – Commitments

Leases – The lease for our corporate office located at 340 Madison Avenue, New York, New York expires on March 31, 2025. Rent expense paid for this operating lease was approximately $110,000 for the three months ended March 31, 2021 and 2020, respectively. The lease for our sales center for 77 Greenwich located at 17 State Street, New York, New York expires on May 31, 2021. Rent expense paid for this operating lease was approximately $65,000 and $92,000 for the three months ended March 31, 2021 and 2020, respectively. The remaining lease obligation, excluding any extension options, for our corporate office and the sales office is approximately $1.9 million.

Legal Proceedings – In the normal course of business, we are party to routine legal proceedings. Based on advice of counsel and available information, including current status or stage of proceeding, and taking into account accruals where they have been established, management currently believes that any liabilities ultimately resulting from litigation we are currently involved in will not, individually or in the aggregate, have a material adverse effect on our consolidated financial position, results of operations or liquidity.

Note 9 – Income Taxes

Effects of the Tax Cuts and Jobs Act

Pursuant to the tax legislation known as the Tax Cuts and Jobs Act (the "TCJA") of 2017, corporate alternative minimum tax (“AMT”) credit carryforwards are eligible for a 50% refund in tax years 2018 through 2020, and beginning in tax year 2021, any remaining AMT credit carryforwards are 100% refundable. As a result of these new rules, as of December 31, 2017 we had released the valuation allowance of $3.1 million formerly reserved against our AMT credit carryforwards and we had recorded a tax benefit and refund receivable of $3.1 million in connection with this valuation allowance release. We received approximately $1.6 million of the refund receivable in October 2019 and the balance of approximately $1.5 million became fully refundable in 2020 as a result of the Coronavirus Aid, Relief, and Economic Security Act, discussed in more detail below, and was received in July 2020.

Other

As of March 31, 2021, we had federal NOLs of approximately $236.3 million. NOLs generated prior to tax-year 2018 will expire in years through fiscal 2037 while NOLs generated in 2018 and forward carry-over indefinitely. The gain resulting from the conveyance of the school condominium to the SCA was fully offset by our available NOL carryforward. Since 2009 through March 31, 2021, we have utilized approximately $23.9 million of our federal NOLs. As of March 31, 2021, we also had state NOLs of approximately $127.5 million. These state NOLs have various expiration dates through 2039, if applicable. We also had New York State and New York City prior NOL conversion (“PNOLC”) subtraction pools of approximately $23.6 million and $18.0 million, respectively. The conversion to the PNOLC under the New York State and New York City corporate tax reforms does not have any material tax impact.

Based on management’s assessment, we believe it is more likely than not that the entire deferred tax assets will not be realized by future taxable income or tax planning strategy. In recognition of this risk, we have provided a valuation allowance of $62.4 million as of March 31, 2021. If our assumptions change and we determine we will be able to realize these NOLs, the tax benefits relating to any reversal of the valuation allowance on deferred tax assets would be recognized as a reduction of income tax expense and an increase in stockholders equity.

On March 27, 2020, the "Coronavirus Aid, Relief, and Economic Security (CARES) Act" was signed into law. The CARES Act, suspended the limitations under the TCJA on the use of NOLs for tax years beginning before January 1, 2021, and allowed losses arising in taxable years beginning after December 31, 2017 and before January 1, 2021 to be carried back up to five years. The CARES Act also accelerated the ability of corporations to recover AMT credits, permitting a full refund for tax years 2018 and 2019. Additionally, the CARES Act included provisions relating to refundable payroll tax credits, deferral of employer side social security payments, modifications to the net interest deduction limitations, increased limitations on qualified charitable contributions, and technical corrections to tax depreciation methods for qualified improvement property. It also appropriated funds for the SBA Paycheck Protection Program loans that are forgivable in certain situations to promote continued employment, as well as Economic Injury Disaster Loans to provide liquidity to small businesses harmed by COVID-19. The CARES Act did not have a material

Table of Contents

impact on our financial position, results of operations or cash flows for the three months ended March 31, 2021 and the year ended December 31, 2020.

Note 10 – Stockholders’ Equity

Capital Stock

Our authorized capital stock consists of 120,000,000 shares consisting of 79,999,997 shares of common stock, $0.01 par value per share, two (2) shares of preferred stock, $0.01 par value per share (which have been redeemed in accordance with their terms and may not be reissued), one (1) share of special stock, $0.01 par value per share, and 40,000,000 shares of a new class of blank-check preferred stock, $0.01 par value per share. As of March 31, 2021 and December 31, 2020, there were 38,840,508 shares and 38,345,540 shares of common stock issued, respectively, and 32,442,633 shares and 32,172,107 shares of common stock outstanding, respectively, with the difference being held in treasury stock.

Warrants

In December 2019, we entered into a Warrant Agreement (the “Warrant Agreement”) with the lender under our Corporate Credit Facility (see Note 5 – Loans Payable and Secured Line of Credit – Corporate Credit Facility) (the “Warrant Holder”) pursuant to which we issued ten-year warrants (the “Warrants”) to the Warrant Holder to purchase up to 7,179,000 shares of our common stock. The Warrants are exercisable immediately and had an exercise price of $6.50 per share (the “Exercise Price”), payable in cash or pursuant to a cashless exercise. The Warrant Agreement provides that we will not issue shares of common stock upon exercise of the Warrants if either (1) the Warrant Holder, together with its affiliates, would beneficially hold 5% or more of the shares of common stock outstanding immediately after giving effect to such exercise, or (2) such exercise would result in the issuance of more than 19.9% of the shares of issued and outstanding common stock as of the date of the Warrant Agreement, prior to giving effect to the issuance of the Warrants, and such issuance would require shareholder approval under the NYSE American LLC listing requirements. On December 22, 2020, the Company entered into the Warrant Agreement Amendment, whereby the exercise price of the warrants issued in connection with the Corporate Credit Facility was amended to be $4.50 per share.

The Warrant Agreement provides for certain adjustments to the Exercise Price and/or the number of shares of common stock issuable upon exercise pursuant to customary anti-dilution provisions. Upon a change of control of the Company, the Warrants will be automatically converted into the right to receive the difference between the consideration the Warrant Holder would have received if it exercised the Warrants immediately prior to the change of control and the aggregate Exercise Price, payable at the election of the Warrant Holder in the consideration payable in the change of control or, if such consideration is other than cash, in cash. The Warrants were valued at approximately $3.2 million and $830,000 at March 31, 2021 and December 31, 2020, respectively. The $2.4 million change in fair value of the Warrants was recorded as an unrealized loss in the consolidated statement of operations and comprehensive loss during the three months ended March 31, 2021.

In connection with the issuance of the Warrants, we also entered into a registration rights agreement with the Warrant Holder, pursuant to which we agreed to register for resale the shares of common stock issuable upon exercise of the Warrants (the “Registration Rights Agreement”), and a letter agreement with the Warrant Holder (the “Letter Agreement”) pursuant to which we agreed to provide (i) certain information rights, (ii) the right to appoint one member of the board of directors of the Company, or in lieu thereof a board observer, and (iii) certain preemptive rights for a period of five years following the exercise of any of the Warrants so long as the Warrant Holder continues to hold shares of common stock. With respect to the board appointment right, the Letter Agreement includes a similar right as the Corporate Credit Facility described in Note 5 – Loans Payable and Secured Line of Credit, so long as the Warrant Holder together with its affiliates beneficially holds at least 5% of the outstanding common stock of the Company, assuming the exercise of all outstanding Warrants; provided that the Warrant Holder does not have such appointment right at any time a Designee or observer may be appointed pursuant to the terms of the Corporate Credit Facility.

At-The-Market Equity Offering Program

In December 2016, we entered into an “at-the-market” equity offering program (the “ATM Program”), to sell up to an aggregate of $12.0 million of our common stock. There were no sales during the periods presented.

Table of Contents

Stock Repurchase Program

In December 2019, our Board of Directors approved a stock repurchase program under which we can buy up to $5.0 million of shares of our common stock, which is now subject to the terms of our Corporate Credit Facility. Repurchases under the stock repurchase program may be made through open market or privately negotiated transactions at times and on such terms and in such amounts as management deems appropriate, subject to market conditions, regulatory requirements and other factors. The program does not obligate the Company to repurchase any particular amount of common stock, and may be suspended or discontinued at any time without notice.

We did not purchase any shares of our common stock during the three months ended March 31, 2021. During the year ended December 31, 2020, we purchased 200,803 shares of our common stock at an average price of $1.67 per share, for a total of 250,197 shares of our common stock purchased at an average price of $1.93 per share since the inception of the stock repurchase program. As of March 31, 2021, approximately $4.5 million of shares remained available for purchase under the stock repurchase program, subject to the terms of our Corporate Credit Facility.

Preferred Stock

We are authorized to issue two shares of preferred stock (one share each of Series A and Series B preferred stock, each of which was automatically redeemed in 2016 and may not be reissued), one share of special stock and 40,000,000 shares of blank-check preferred stock. The share of special stock was issued and sold to Third Avenue Trust, on behalf of Third Avenue Real Estate Value Fund ("Third Avenue"), and enables Third Avenue or its affiliated designee to elect one member of the Board of Directors.

Note 11 – Stock-Based Compensation

Stock Incentive Plan

We adopted the Trinity Place Holdings Inc. 2015 Stock Incentive Plan (the “SIP”), effective September 9, 2015. Prior to the adoption of the SIP, we granted restricted stock units (“RSUs”) to our executive officers and employees pursuant to individual agreements. The SIP, which has a ten-year term, authorizes (i) stock options that do not qualify as incentive stock options under Section 422 of the Code, or NQSOs, (ii) stock appreciation rights, (iii) shares of restricted and unrestricted common stock, and (iv) RSUs. The exercise price of stock options will be determined by the compensation committee, but may not be less than 100% of the fair market value of the shares of common stock on the date of grant. To date, no stock options have been granted under the SIP. The SIP initially authorized the issuance of up to 800,000 shares of common stock. In June 2019, our stockholders approved an amendment and restatement of the SIP, including an increase to the number of shares of common stock available for awards under the SIP by 1,000,000 shares. Our Board has approved, subject to stockholder approval at the 2021 annual shareholder meeting, an increase in the number of shares of common stock available for awards under the SIP by 1,500,000. Our SIP activity as of March 31, 2021 and December 31, 2020 was as follows:


	Three Months Ended			Year Ended
	March 31, 2021			December 31, 2020
		Weighted			Weighted
		Average Fair			Average Fair
	Number of	Value at		Number of	Value at
	Shares	Grant Date		Shares	Grant Date
Balance available, beginning of period	548,370			1,017,535
Granted to employees	(310,000)	$	1.25	(295,500)	$	3.01
Granted to non-employee directors	(21,627)	$	1.25	(59,660)	$	1.65
Deferred under non-employee director's deferral program	(38,100)	$	1.25	(114,005)	$	1.76
Balance available, end of period	178,643			548,370

Table of Contents

Restricted Stock Units

We grant RSUs to certain executive officers and employees as part of compensation. These grants generally have vesting dates ranging from immediate vest at grant date to three years, with a distribution of shares at various dates ranging from the time of vesting up to seven years after vesting.

During the three months ended March 31, 2021, we granted 310,000 RSUs to certain employees. These RSUs vest and settle at various times over a two or three year period, subject to each employee’s continued employment. Approximately $64,000 in compensation expense related to these shares was amortized during the three months ended March 31, 2021, of which approximately $20,000 was capitalized into real estate under development.

Total stock-based compensation expense recognized in the consolidated statements of operations and comprehensive loss during the three months ended March 31, 2021 and 2020 totaled $151,000 and $177,000, respectively, which is net of $45,000 and $91,000 capitalized as part of real estate under development, respectively.

Our RSU activity was as follows:


	Three Months Ended			Year Ended
	March 31, 2021			December 31, 2020
		Weighted			Weighted
		Average Fair			Average Fair
	Number of	Value at Grant		Number of	Value at Grant
	Shares	Date		Shares	Date
Non-vested at beginning of period	469,000	$	3.43	453,334	$	5.00
Granted RSUs	310,000	$	1.25	295,500	$	3.01
Vested	(207,917)	$	3.59	(279,834)	$	5.46
Non-vested at end of period	571,083	$	2.19	469,000	$	3.43

As of March 31, 2021, there was approximately $661,000 of total unrecognized compensation expense related to unvested RSUs, which is expected to be recognized through December 2023.

During the three months ended March 31, 2021, we issued 473,343 shares of common stock to employees and executive officers to settle vested RSUs from previous RSU grants. In connection with those transactions, we repurchased 224,442 shares to provide for the employees’ withholding tax liabilities.

During the three months ended March 31, 2021, we issued 21,627 shares of immediately vested common stock to board members as part of their annual compensation.

Director Deferral Program

Our Non-Employee Director’s Deferral Program (the “Deferral Program”), as amended in December 2018, allows our non-employee directors to elect to receive the cash portion of their annual compensation in shares of the Company’s common stock, as well as to defer receipt of the portion of their annual board compensation that is paid in equity. Any deferred amounts are paid under the SIP (as is non-employee directors’ annual equity compensation that is not deferred). Compensation deferred under the Deferral Program is reflected by the grant of stock units equal to the number of shares that would have been received absent a deferral election. The stock units, which are fully vested at grant, generally will be settled under the SIP for an equal number of shares of common stock within 10 days after the participant ceases to be a director. In the event that we distribute dividends, each participant shall receive a number of additional stock units (including fractional stock units) equal to the quotient of (i) the aggregate amount of the dividend that the participant would have received had all outstanding stock units been shares of common stock divided by (ii) the closing price of a share of common stock on the date the dividend was issued.

As of March 31, 2021, a total of 215,259 stock units have been deferred under the Deferral Program.

Table of Contents

Note 12 – Investments in Unconsolidated Joint Ventures

We own a 50% interest in a joint venture (the “Berkley JV”) formed to acquire and operate The Berkley, a recently built 95-unit multi-family property. In December 2016, the Berkley JV closed on the acquisition of The Berkley for a purchase price of $68.885 million, of which $42.5 million was financed through a 10-year loan (the “Berkley Loan”) secured by The Berkley, and the balance was paid in cash, half of which was funded by us. The non-recourse Berkley Loan bore interest at the 30-day LIBOR rate plus 216 basis points, was interest only for five years, was pre-payable after two years with a 1% prepayment premium and had covenants and defaults customary for a Freddie Mac financing. On February 28, 2020, in connection with a refinancing, the Berkley JV repaid the Berkley Loan in full and replaced it with a new 7-year, $33.0 million loan (the “New Berkley Loan”) which bears interest at a fixed rate of 2.717% and is interest only during the initial five years. It is pre-payable at any time and can be increased by up to $6.0 million under certain circumstances. We and our joint venture partner are joint and several recourse carve-out guarantors under the New Berkley Loan.

We own a 10% interest in a joint venture with TF Cornerstone (the “250 North 10^th JV”) formed to acquire and operate 250 North 10^th, a recently built 234-unit apartment building in Williamsburg, Brooklyn, New York. On January 15, 2020, the 250 North 10^th JV closed on the acquisition of the property for a purchase price of $137.75 million, of which $82.75 million was financed through a 15-year mortgage loan (the “250 North 10^th Note”) secured by 250 North 10^th and the balance was paid in cash. Our share of the equity totaling approximately $5.9 million was funded through a loan (the “Partner Loan”) from our joint venture partner. The Partner Loan bears interest at 7.0% which is payable to the extent of available cash flow and is prepayable any time within its four year term. Our partner has the option of having the Partner Loan repaid in our common stock if the price of our common stock exceeds $6.50 per share at the time of conversion. The non-recourse 250 North 10^th Note bears interest at 3.39% for the duration of the loan term and has a non-recourse carve out guaranty executed by us. We earned an acquisition fee at closing and are entitled to ongoing asset management fees and a promote upon the achievement of certain performance hurdles.

As of March 31, 2021, we have one unconsolidated VIE, namely 250 North 10^th. We do not consolidate this entity because we are not the primary beneficiary and the nature of our involvement in the activities of this entity does not give us power over decisions that significantly affect this entity’s economic performance. We account for our investment in this entity under the equity method (see Note 2 – Summary of Significant Accounting Policies – Basis of Presentation – Principles of Consolidation). As of March 31, 2021, the net carrying amount of our investment in this entity was $5.2 million and our maximum exposure to loss in this entity is limited to the carrying amount of our investment.

As we do not control these joint ventures, we account for them under the equity method of accounting. During the three months ended March 31, 2021, we recognized our share of the fair value liability associated with an interest rate swap

Table of Contents

entered into on February 28, 2020 of approximately $198,000. The combined balance sheets for our unconsolidated joint ventures at March 31, 2021 and December 31, 2020 are as follows (in thousands):


	March 31,		December 31,
	2021		2020

ASSETS

Real estate, net	$	166,784	$	167,749
Cash and cash equivalents		1,307		1,344
Restricted cash		835		766
Tenant and other receivables, net		247		254
Prepaid expenses and other assets, net		231		204
Intangible assets, net		23,275		24,006
Total assets	$	192,679	$	194,323

LIABILITIES

Mortgages payable, net	$	112,960	$	114,218
Accounts payable and accrued expenses		1,823		1,705
Total liabilities		114,783		115,923

MEMBERS’ EQUITY

Members’ equity		91,074		92,070
Accumulated deficit		(13,178)		(11,943)
Accumulated other comprehensive loss		—		(1,727)
Total members’ equity		77,896		78,400

Total liabilities and members’ equity	$	192,679	$	194,323

Our investments in unconsolidated joint ventures	$	18,814	$	19,379

Table of Contents

The statements of operations for our unconsolidated joint ventures for the three months ended March 31, 2021 and 2020 are as follows (in thousands):


	For the Three Months Ended		For the Three Months Ended
	March 31,		March 31,
	2021		2020
	(unaudited)		(unaudited)
Revenues
Rental revenues	$	2,979	$	2,998

Total revenues		2,979		2,998

Operating Expenses
Property operating expenses		1,065		706
Real estate taxes		25		11
General and administrative		2		2
Amortization		731		1,251
Depreciation		984		876

Total operating expenses		2,807		2,846

Operating income		172		152

Interest expense, net		(939)		(954)
Interest expense -amortization of deferred finance costs		(72)		(1,666)
Interest expense -change in fair market value of interest rate swap		(396)		—

Net loss	$	(1,235)	$	(2,468)

Our equity in net loss from unconsolidated joint ventures	$	(372)	$	(991)

Note 13 – Subsequent Events

We have performed subsequent event procedures through the date the consolidated financial statements were available to be issued, and there were no subsequent events requiring adjustment to, or disclosure in, the consolidated financial statements.

Table of Contents

Item 2. Management’s Discussion and Analysis of Financial Condition and Results of Operations

Overview

Trinity Place Holdings Inc. which we refer to in this report as “Trinity,” “we,” “our,” or “us”, is a real estate holding, investment, development and asset management company. Our largest asset is currently a property located at 77 Greenwich Street in Lower Manhattan (“77 Greenwich”). 77 Greenwich was previously a vacant building that we demolished. It is under development as a mixed-use project consisting of a 90-unit residential condominium tower, retail space and a New York City elementary school. We also own a recently built 105-unit, 12-story multi-family property located at 237 11^th Street in Brooklyn, New York (“237 11^th”), acquired in May 2018, and, through joint ventures, a 50% interest in a recently built 95-unit multi-family property known as The Berkley, located at 223 North 8^th Street, Brooklyn (“The Berkley”) and a 10% interest in a recently built 234-unit multi-family property located one block from The Berkley at 250 North 10^th Street (“250 North 10^th”) acquired in January 2020, also in Brooklyn, New York. In addition we own a property occupied by retail tenants in Paramus, New Jersey. See Properties below for a more detailed description of our properties. In addition to our real estate portfolio, we also control a variety of intellectual property assets focused on the consumer sector, a legacy of our predecessor, Syms Corp. (“Syms”). We also had approximately $236.3 million of federal net operating loss carry forwards (“NOLs”) at March 31, 2021, which can be used to reduce our future taxable income and capital gains.

We continue to evaluate new investment opportunities, with a focus on newly constructed multi-family properties in New York City as well as properties in close proximity to public transportation in the greater New York metropolitan area. We consider investment opportunities involving other types of properties and real estate related assets, as well as repurchases of our common stock, taking into account our cash position, liquidity requirements, and our ability to raise capital to finance our growth. In addition, we may selectively consider potential acquisition, development and fee-based opportunities, as well as disposition, sale or consolidation opportunities.

Impact of COVID-19

The impact of the recent outbreak of COVID-19 on our results and operations has been and will continue to be significant. The extent of the impact going forward will largely depend on future developments, which are highly uncertain and cannot be predicted, including the severity and duration of the outbreak, in New York City in particular, the success of actions taken to contain or treat COVID-19, actions taken by governmental entities, companies and individuals in response to the pandemic and reactions to such actions, the impact on local and broader economic activity and capital markets from the COVID-19 pandemic and new information that emerges with respect to the foregoing and other aspects of COVID-19. The extent to which the COVID-19 pandemic will impact the Company’s business, operations and financial results in the future will depend on numerous evolving factors that the Company is not able to predict at this time, including, but not limited to, the impact on sales of residential condominium units at our most significant asset, 77 Greenwich, which has been material, the impact on the timing for construction of 77 Greenwich and completion of the remediation and restoration project at 237 11^th; the impact on the timing of the 237 11^th litigation due to backlog in the New York City court system and the slowdown in judicial proceedings, and the receipt of any payments we may receive in connection with the litigation; our ability to obtain maturity extensions and covenant modifications on acceptable terms; increased operating costs related to cleaning and disinfecting our properties; the effect of the pandemic on the Company’s tenants and their ability to make rental payments; and the effect of the eviction moratorium (in effect from March 2020 through August 31, 2021, subject to further extension) imposed by New York State and the impact of decisions of the NYC Rent Guidelines Board on our ability to raise rents. These developments and events have and will continue to adversely impact the Company’s business, financial condition, results of operations and stock price, which has been and is anticipated to continue to be material, although in recent months we have seen indications of a recovery in the New York City real estate market and improvements in the financing markets, including early indications of robust interest in the refinancing of our two loans maturing in June 2021 and January 2022, respectively. See Note 1 – Business to our consolidated financial statements and Part II. Item 1A. Risk Factors, of this Quarterly Report on Form 10-Q for further information.

Vacancy rates for multifamily properties across all boroughs of New York City have increased since the start of the COVID-19 pandemic, with the largest increases in Manhattan. The work from home phenomenon resulted in significant number of people moving out of urban areas to suburban areas. This has driven a drop in rental rates and an increase in concessions resulting in lower net effective rents primarily on new leases. In recent months, with the implementation of COVID-19 vaccination programs and companies encouraging employees to return to the office, more potential tenants are moving back into New York City, which we anticipate should result in a reduction in concessions over time. New York State imposed a moratorium on tenant evictions in March 2020 that will be in place until August 31, 2021, unless extended

Table of Contents

further. Rent collections at our properties have been strong and in line with pre-pandemic collection rates. Notwithstanding these broader market trends, although multifamily property sales transaction volumes decreased in 2020, signs of distress, including discounted sales prices and debt workouts, in the New York City investment market has been almost non-existent over the past year.

Properties

Below is certain information regarding our real estate properties as of March 31, 2021:


		Building Size
		(estimated		Leased at
		rentable	Number of	March 31,
Property Location	Type of Property	square feet)	Units	2021
Owned Locations

77 Greenwich, New York, New York (1)	Property under development	—	—	N/A

Paramus, New Jersey (2)	Property under development	77,000	—	100.0	%

237 11^th Street, Brooklyn, New York (3)	Multi-family	80,000	105	28.6	%

Total		157,000	105

Joint Ventures

223 North 8^th Street, Brooklyn, New York - 50% (4)	Multi-family	65,000	95	100.0	%
250 North 10^th Street, Brooklyn, New York - 10% (5)	Multi-family	158,000	234	97.4	%

Total		223,000	329

Grand Total		380,000	434

(1)

77 Greenwich. We are currently nearing completion of the development stage for the development of an over 300,000 gross square foot mixed-use building that corresponds to the approximate total of 233,000 zoning square feet. The plans call for the development of 90 luxury residential condominium apartments, 7,500 square feet of retail space, almost all of which is street level, a 476-seat elementary school serving New York City District 2, including the adaptive reuse of the landmarked Robert and Anne Dickey House, and construction of a new handicapped accessible subway entrance on Trinity Place. In early April 2020, New York State required all non-essential construction projects be shut down due to the impact of the COVID-19 pandemic. As a result, the construction of 77 Greenwich was temporarily suspended. Construction recommenced mid-April, initially on a modified basis, as certain work was deemed “essential” construction. Since June 2020, a full crew has been on site and operating in accordance with applicable guidelines in response to the COVID-19 outbreak. As of March 31, 2021, 100% of the building enclosure is complete (excluding the hoist area), tile and stone was installed up to the 29^th floor, wood flooring was installed up to the 26^th floor, kitchen cabinets were installed through the 24^th floor, and appliances were installed through the 21^st floor. We have also completed the build-out and furnishing of the model units and moved the sales gallery to the building. The attorney general’s office approved our condominium offering plan in April 2019. Marketing of residential units for sale commenced during the spring 2019 and the Company has commenced entering into sales agreements with purchasers of the residential condominium units. Although sales activity has recently begun to increase from 2020 levels, through December 31, 2020 sales activity was limited due to being adversely impacted by the pandemic and the local New York City economy. In December 2017, we closed on a $189.5 million construction facility, which was paid down by $8.0 million in December 2020. We draw down proceeds under the construction facility as costs related to the construction are incurred, with an aggregate of $145.9 million having been drawn as of March 31, 2021. We currently anticipate that the proceeds available under the construction facility, together with equity funded by us to date and contributions by the New York City School Construction Authority (the “SCA”), will be sufficient to fund the construction and development of 77 Greenwich without us making any further equity contributions (see Note 5 – Loans Payable and Secured Line of Credit to our consolidated financial statements for further information).

Table of Contents

for the purchase of their condominium unit and reimburse us for the costs associated with constructing the school, including a construction supervision fee of approximately $5.0 million payable to us. Payments for construction are being made by the SCA to the general contractor in installments as construction on their condominium unit progresses. Payments to us for the land and construction supervision fee commenced in January 2018 and continued through October 2019 for the land and will continue through the second quarter of 2021 for the construction supervision fee, with an aggregate of $46.0 million having been paid to us as of March 31, 2021 from the SCA, with $333,000 remaining to be paid. We have also received an aggregate of $49.3 million in reimbursable construction costs from the SCA through March 31, 2021. The SCA closed on the purchase of the school condominium unit with us in April 2020, at which point title transferred to the SCA, and the SCA is now proceeding to complete the buildout of the interior space, which is planned to become an approximately 476 seat public elementary school. Upon conveyance, we recognized a gain on the sale of approximately $20.0 million and an additional gain of $4.2 million related to the recognition of our deferred construction supervision fee, and our liquidity requirement on the 77 Greenwich Construction Facility decreased from $15.0 million to $10.0 million. This liquidity requirement was further reduced to $8.0 million in March 2021 upon the receipt of our first temporary certificate of occupancy (“TCO”). The pace of completion of the buildout by the SCA has been impacted by COVID-19 and its scheduled timeline is currently anticipated to be August 2022.

Prior to the COVID-19 related shutdown of all non-essential construction by New York State in early April 2020, the residential condominium units were scheduled to be completed by the end of 2020. Future delays in construction may result in a delay in our ability to complete the construction project on its original timeline and our ability to sell condominium units. In December 2020, we amended certain provisions of the 77 Greenwich Construction Facility to provide more flexibility under the sales pace covenant and other financial covenants (see Note 5 – Loans Payable and Secured Line of Credit to our consolidated financial statements for further information). We currently anticipate receiving our TCOs in stages throughout 2021, with the first TCO having been received on March 8, 2021.

(2)

Paramus Property. The Paramus property consists of a one-story and partial two-story, 73,000 square foot freestanding building and an outparcel building of approximately 4,000 square feet, for approximately 77,000 total square feet of rentable space. The primary building is comprised of approximately 47,000 square feet of ground floor space, and two separate mezzanine levels of approximately 21,000 and 5,000 square feet. The 73,000 square foot building is leased to Restoration Hardware Holdings, Inc. (NYSE: RH) (“Restoration Hardware”) pursuant to a license agreement that began on June 1, 2016, which is terminable upon three months’ notice, and currently is scheduled to end on March 31, 2023. The outparcel building is leased to a long-term tenant whose lease expires on March 31, 2022. The land area of the Paramus property consists of approximately 292,000 square feet, or approximately 6.7 acres. During the three months ended March 31, 2021, we collected 100% of rent due.

We are currently exploring options with respect to the Paramus property, including development or sale, among others.

(3)

237 11^th Street. In May 2018, we closed on the acquisition of a recently built 105-unit, 12-story multi-family apartment building encompassing approximately 93,000 gross square feet (approximately 80,000 rentable square feet) located at 237 11^th Street, Park Slope, Brooklyn, New York for a purchase price of $81.2 million, excluding transaction costs of approximately $0.7 million. The property also includes 6,264 square feet of retail space, more than half of which is leased to Starbucks Inc. (NQGS:SBUX) and an oral surgeon. Located on the border of the Park Slope and Gowanus neighborhoods of Brooklyn, the property is located one block from the 4th Avenue/9th Street subway station. The 237 11^th property offers an array of modern amenities that surpass what is available in the neighborhood’s “brownstone” housing stock. The property also benefits from a 15-year Section 421-a real estate tax exemption.

Due to certain construction defects at 237 11^th that resulted in water penetration into the building and damage to certain apartment units and other property, which defects we believe were concealed and which would have required significant invasive work of a type not usually required or permitted, especially on a newly-built asset, to be detected, we submitted proofs of loss to our insurance carrier for property damage and business interruption (lost revenue) in March 2019. The insurance carrier subsequently disclaimed coverage for the losses and we filed a complaint against the carrier and its administrator, alleging that they breached the insurance policy by denying coverage and requesting a declaration that they are obligated to cover the claimed damage. We also filed legal claims against the seller, its parent company, and the general contractor to recover damages arising from the defective construction. In addition, the general contractor impleaded into that litigation several subcontractors who performed work on the property. Management expects to recover some portion of the cost incurred to repair the property through the litigations and/or settlement negotiations with the seller, its parent company, the general contractor, the subcontractors, and the insurance carrier, although the amount of damages that may be recoverable in litigation and/or potential settlement

Table of Contents

negotiations are uncertain at this time, as is receipt of any such payments, which has been impacted by the COVID-19 pandemic, including the resulting backlog in the court system and slowdown in the judicial proceedings. We have been in discussions with the seller, its parent company, the general contractor, and the third-party defendants impleaded by the general contractor about engaging in mediation to potentially settle the case involving those parties. A mediation process commenced at the end of February 2021. We incurred significant cash outflows for costs associated with these repairs and remediation, which commenced in September 2019. Remediation and restoration work was delayed for two months in 2020 due to the temporary shutdown of non-essential construction projects in New York from April to June, which resulted in a delay in commencement of our leasing up of the property. Future delays would have a similar impact. As of March 31, 2021, remediation work on floors 3-12 had been completed, other than a few specific units. We expect the remediation and restoration project to be completed by summer 2021. As of March 31, 2021, 83 units had been remediated, many of which are now occupied. We also began leasing efforts for the remediated units and have seen an increase in traffic to view these units. Additional units will be introduced back into the market as they become available. During the three months ended March 31, 2021, we collected 100% of rent due. As of April 30, 2021, the property was approximately 43% leased.

(4)

223 North 8^th Street. Through a joint venture, we own a 50% interest in the entity formed to acquire and operate The Berkley, a recently built 95-unit multi-family property encompassing approximately 99,000 gross square feet (65,000 rentable square feet) at 223 North 8^th Street in North Williamsburg, Brooklyn, New York. The Berkley is in close proximity to public transportation and offers a full amenity package. Apartments feature top-of-the-line unit finishes, central air conditioning and heating and most units have private outdoor space. The property benefits from a 25-year Section 421-a real estate tax exemption. During the three months ended March 31, 2021, The Berkley collected 100% of rent due. As of April 30, 2021, the property was 100% leased.

(5)

250 North 10^th Street. Through a joint venture, we own a 10% interest in the entity formed to acquire and operate 250 North 10^th Street, a recently built 234-unit apartment building in Williamsburg, Brooklyn, New York. The property is four blocks from the Bedford Avenue L subway station and a short walk from the Metropolitan Avenue G subway station as well as the J, M, and Z trains at Marcy Avenue. It is located one block from The Berkley. Apartments feature top-of-the-line unit finishes including GE stainless steel appliances, caesarstone countertops, in-unit washers and dryers, individually zoned climate controls, floor to ceiling windows and oak hardwood floors. In addition, the property offers a full amenity package including a concierge, a resident’s lounge with roof deck, a fitness center, a café lounge and an expansive terrace, tenant storage, parking, and sweeping views of the neighborhood and Manhattan. The property has approximately eight years remaining on its 15-year Section 421-a real estate tax exemption. Although all apartments are market rate units, they are subject to New York City’s rent stabilization law during the remaining term of the Section 421-a real estate tax exemption. During the three months ended March 31, 2021, 250 North 10^th Street collected approximately 92.9% of rent due. As of April 30, 2021, the property was 100% leased.

Lease Expirations

As of March 31, 2021, we have one retail lease at our Paramus property with 4,000 square feet of leased space with annualized rent of $140,000 per year that expires in 2022, a retail lease at the 237 11^thproperty with 2,006 square feet of leased space with annualized rent of $130,000 per year that expires in 2027 and a second retail lease at the 237 11^thproperty with 1,074 square feet of leased space with average annualized rent of $92,675 per year that expires in 2036. All our other leases are residential leases which expire within twelve or twenty-four months of the commencement date.

Critical Accounting Policies and Estimates

Management’s discussion and analysis of financial condition and results of operations is based upon our consolidated financial statements, which have been prepared in accordance with generally accepted accounting principles in the United States of America (“GAAP”). The preparation of financial statements in conformity with GAAP requires the use of estimates and assumptions that could affect the reported amounts in our consolidated financial statements. Actual results could differ from these estimates. A summary of our significant accounting policies that management believes are critical to the preparation of the consolidated financial statements are included in this report (see Note 2 - Summary of Significant Accounting Policies - Basis of Presentation to our consolidated financial statements for further information). Certain of the accounting policies used in the preparation of these consolidated financial statements are particularly important for an understanding of the financial position and results of operations presented in the historical consolidated financial statements included in this report and require the application of significant judgment by management and, as a result, are subject to a degree of uncertainty. We believe there have been no material changes to the items that we disclosed as our

Table of Contents

critical accounting policies under Item 7, “Management’s Discussion and Analysis of Financial Condition and Results of Operations,” in our 2020 Annual Report on Form 10-K (the “2020 Annual Report”) for the year ended December 31, 2020.

The following discussion and analysis is intended to assist readers in understanding our financial condition and results of operations during the three months ended March 31, 2021 and 2020 and should be read in conjunction with the consolidated financial statements and notes thereto included in this Quarterly Report on Form 10-Q and our 2020 Annual Report.

Results of Operations for the Three Months Ended March 31, 2021 Compared to the Three Months Ended March 31, 2020

Rental revenues in total decreased by approximately $28,000 to $299,000 for three months ended March 31, 2021 from $327,000 for the three months ended March 31, 2020. This consisted of a decrease in rent revenues by approximately $30,000 to $286,000 for the three months ended March 31, 2021 from $316,000 for the three months ended March 31, 2020, offset by an increase in tenant reimbursements by approximately $2,000 to $13,000 for the three months ended March 31, 2021 from $11,000 for the three months ended March 31, 2020. The decrease in total revenues and its related components was due to lower occupancy, lower face rents and increased rent concessions at 237 11^th due to certain construction related defects that are being repaired.

Other income of $46,000 consisted mainly of the SCA construction supervision fees we recognized during the three months ended March 31, 2021 in accordance with the revenue recognition policies effective after the closing on the sale of the school condominium to the SCA in April 2020.

Property operating expenses increased by approximately $61,000 to $1.7 million for the three months ended March 31, 2021 from $1.6 million for the three months ended March 31, 2020. The increase was principally due to expenses associated with 237 11^th, including approximately $140,000 in increased costs incurred during the three months ended March 31, 2021 compared to the three month ended March 31, 2020 to repair the construction related defects. Property operating expenses consisted primarily of expenses incurred for utilities, payroll, COVID-19 related supplies and general operating expenses as well as repairs and maintenance at 237 11^th.

Real estate tax expense for the three months ended March 31, 2021 remained consistent with the three months ended March 31, 2020 at $20,000.

General and administrative expenses decreased by approximately $131,000 to $1.2 million for the three months ended March 31, 2021 from $1.3 million for the three months ended March 31, 2020. For the three months ended March 31, 2021, approximately $106,000 related to stock-based compensation, $698,000 related to payroll and payroll related expenses, $253,000 related to other corporate expenses, including board fees, corporate office rent and insurance and $146,000 related to legal, accounting and other professional fees. For the three months ended March 31, 2020, approximately $177,000 related to stock-based compensation, $722,000 related to payroll and payroll related expenses, $244,000 related to other corporate expenses, including board fees, corporate office rent and insurance and $191,000 related to legal, accounting and other professional fees.

Pension related costs decreased by approximately $2,000 to $163,000 for the three months ended March 31, 2021 from $165,000 for the three months ended March 31, 2020. These costs represent professional fees and other periodic pension costs incurred in connection with the legacy Syms Pension Plan (see Note 7 – Pension Plans to our consolidated financial statements for further information).

Transaction related costs decreased by approximately $14,000 to $1,000 for the three months ended March 31, 2021 from $15,000 for the three months ended March 31, 2020. These costs represent professional fees and other costs incurred in connection with the underwriting and evaluation of potential acquisitions and investments for transactions that were not consummated, as well as costs for potential leases at our retail properties that were not consummated.

Depreciation and amortization increased by approximately $114,000 to $715,000 for the three months ended March 31, 2021 from $601,000 for the three months ended March 31, 2020. For the three months ended March 31, 2021, depreciation and amortization expense consisted of depreciation for 237 11^th of approximately $381,000 and the amortization of lease commissions, acquired in-place leases and warrants of approximately $334,000. For the three months ended March 31, 2020, depreciation and amortization expense consisted of depreciation for 237 11^th property of approximately $380,000 and the amortization of trademarks and lease commissions and acquired in-place leases of approximately $221,000. The

Table of Contents

increase in depreciation and amortization expense for the three months ended March 31, 2021 compared to March 31, 2020 was primarily due to amortization of warrants.

Equity in net loss from unconsolidated joint ventures decreased by approximately $619,000 to $372,000 for the three months ended March 31, 2021 from $991,000 for the three months ended March 31, 2020 primarily due to approximately $800,000 of our portion of the write-off of deferred finance costs in connection with the refinancing of the Berkley Loan during the three months ended March 31, 2020. Equity in net loss from unconsolidated joint ventures represents our 50% share in The Berkley and our 10% share in 250 North 10^th. For the three months ended March 31, 2021, our share of the loss is primarily comprised of operating income before depreciation of $385,000 offset by depreciation and amortization of $374,000, interest expense of $184,000 and the change in fair value of interest rate swap of $199,000. For the three months ended March 31, 2020, our share of the loss is primarily comprised of operating income before depreciation of $466,000 offset by depreciation and amortization of $1.2 million and interest expense of $241,000.

Unrealized loss on warrants increased by approximately $3.2 million to a $2.0 million loss for the three months ended March 31, 2021 from a gain of $1.2 for the three months ended March 31, 2020. This represents the change in the mark-to-market of the valuation of warrants.

Interest expense, net increased by approximately $605,000 to $601,000 million for the three months ended March 31, 2021 from $4,000 of interest income, net for the three months ended March 31, 2020. For the three months ended March 31, 2021, there was approximately $5.0 million of gross interest expense incurred, $4.4 million of which was capitalized, and no interest income. For the three months ended March 31, 2020, there was approximately $4.0 million of gross interest expense incurred, all of which was capitalized, and $4,000 of interest income. The increase in gross interest expense is due to the larger and growing borrowings outstanding on the 77 Greenwich Construction Facility during the period, as well as new borrowings under the Corporate Credit Facility, Mezzanine Loan and secured line of credit as described in more detail in the Liquidity and Capital Resources section below.

Interest expense - amortization of deferred finance costs of $193,000 for the three months ended March 31, 2021 represents the amount of amortization of finance costs for our loans and secured line of credit that were not capitalized as part of real estate under development.

We recorded $35,000 in tax expense for the three months ended March 31, 2021 compared to $65,000 in tax in expense for the three months ended March 31, 2020.

Net loss attributable to common stockholders increased by approximately $3.3 million to $6.6 million for the three months ended March 31, 2021 from a loss of $3.3 million for the three months ended March 31, 2020 as a result of the changes discussed above, principally the increase in unrealized loss on warrants of $3.2 million.

Liquidity and Capital Resources

We currently expect that our principal sources of funds to meet our short-term and long-term liquidity requirements for working capital and funds for acquisition and development or redevelopment of properties, tenant improvements, leasing costs, and repayments of outstanding indebtedness will include some or all of the following:

(1)	cash on hand;

(2)	proceeds from new debt financings, increases to existing debt financings and/or other forms of secured or unsecured debt financing;

(3)	proceeds from equity or equity-linked offerings, including rights offerings or convertible debt or equity or equity-linked securities issued in connection with debt financings;

(4)	cash flow from operations; and

(5)	net proceeds from divestitures of properties or interests in properties.

Cash flow from operations is primarily dependent upon the occupancy level of our portfolio, the net effective rental rates achieved on our leases, the collectability of rent, operating escalations and recoveries from our tenants and the level of operating and other costs.

As of March 31, 2021, we had total cash and restricted cash of $11.7 million, of which approximately $5.0 million was cash and cash equivalents and approximately $6.7 million was restricted cash. As of December 31, 2020, we had total cash

Table of Contents

and restricted cash of $16.1 million, of which approximately $6.5 million was cash and cash equivalents and approximately $9.6 million was restricted cash. Restricted cash represents amounts required to be restricted under our loan agreements, letters of credit (see Note 5 – Loans Payable and Secured Line of Credit to our consolidated financial statements for further information), deposits on condominium sales at 77 Greenwich and tenant related security deposits. In addition, cash and cash equivalents includes cash which, together with availability under our line of credit, is required to be maintained to meet certain liquidity requirements under the 77 Greenwich Construction Facility, described below. This liquidity requirement, inclusive of cash and line of credit availability, decreased to $10.0 million when we closed on the conveyance of the school condominium to the SCA in April 2020, decreased to $8.0 million upon obtaining the first TCO and decreases further upon the achievement of certain construction related milestones at 77 Greenwich.

Corporate Credit Facility

In December 2019, we entered into a credit agreement (the “Corporate Credit Facility”) with an affiliate of a global institutional investment management firm as initial lender (the “CCF Lender”) and Trimont Real Estate Advisors, LLC, as administrative agent (the “Corporate Facility Administrative Agent”), pursuant to which the CCF Lender agreed to extend us credit in multiple draws aggregating $70.0 million, which may be increased by $25.0 million subject to satisfaction of certain conditions and the consent of the CCF Lender. Draws under the Corporate Credit Facility may be made during the 32-month period following the closing date of the Corporate Credit Facility (the “Closing Date”). The Corporate Credit Facility matures on December 19, 2024, subject to extensions until December 19, 2025 and June 19, 2026, respectively, under certain circumstances. The proceeds of the Corporate Credit Facility may be used for investments in certain multi-family apartment buildings in the greater New York City area and certain non-residential real estate investments approved by the CCF Lender in its reasonable discretion, as well as in connection with certain property recapitalizations and in specified amounts for general corporate purposes and working capital. The Corporate Credit Facility bears interest at a rate per annum equal to the sum of (i) 5.25% and (ii) a scheduled interest rate (the “Cash Pay Interest Rate”) based on six-month periods from the Closing Date, which Cash Pay Interest Rate, from the Closing Date until the six-month anniversary of the Closing Date initially equaled 4.0% and increases by 125 basis points in each succeeding six-month period, subject to increase during the extension periods. A $2.45 million commitment fee was payable 50% on the initial draw and 50% as amounts under the Corporate Credit Facility are drawn, with any remaining balance due on the last date of the draw period, and a 1.0% exit fee is payable in respect of Corporate Credit Facility repayments. As of March 31, 2021, we had paid $1.85 million of the commitment fee. The Corporate Credit Facility may be prepaid at any time subject to a prepayment premium on the portion of the Corporate Credit Facility being repaid. At March 31, 2021, the Corporate Credit Facility had an outstanding balance of $35.75 million, excluding deferred finance fees of $3.6 million, and an effective interest rate of 9.5%. Accrued interest totaled approximately $2.0 million at March 31, 2021. (See Note 5 – Notes Payable and Secured Line of Credit to our consolidated financial statements for further discussion).

In connection with the December 2020 transaction noted below, the Company entered into an amendment to the Corporate Credit Facility (the “Corporate Facility Amendment”) pursuant to which, among other things, (i) the CCF Lender and the Corporate Facility Administrative Agent permitted the Company to enter into the Mezzanine Loan Agreement (as defined below), the amendment to the 77 Greenwich Construction Facility (as defined below) and related documents, (ii) the commitment made by the CCF Lender under the Corporate Credit Facility was reduced by the amount of the Mezzanine Loan (as defined below) from $70.0 million to $62.5 million, subject to increase by $25.0 million upon satisfaction of certain conditions and the consent of the CCF Lender, and (iii) the multiple on invested capital, or MOIC, amount that would be due and payable by the Company upon the final repayment of the loan pursuant to the Corporate Credit Facility if no event of default exists and is continuing under the Corporate Credit Facility at any time prior to December 22, 2022, was amended to combine the Corporate Credit Facility and the Mezzanine Loan for purposes of calculating the MOIC, to the extent not previously paid, if any.

In connection with the Corporate Credit Facility, we also entered into a warrant agreement with the CCF Lender pursuant to which we issued to the CCF Lender ten-year warrants (the “Warrants”) to purchase up to 7,179,000 shares of our common stock. In connection with the Corporate Facility Amendment, the exercise price of the Warrants was amended from $6.50 per share to $4.50 per share, payable in cash or pursuant to a cashless exercise (see Note 10 – Stockholders Equity – Warrants to our consolidated financial statements for further discussion regarding the warrants).

Table of Contents

237 11^th Loans

In May 2018, in connection with the acquisition of 237 11^th, we entered into two-year interest-only financings with an aggregate principal amount of $67.8 million, comprised of a $52.4 million mortgage loan (the “237 11^th Loan”) with Canadian Imperial Bank of Commerce (“CIBC”) and a $15.4 million mezzanine loan with RCG LV Debt VI REIT, LLC bearing interest at a blended average rate of 3.72% over the 30-day LIBOR, each with a one-year extension option upon satisfaction of certain conditions. The mezzanine loan was repaid in full in February 2020. In June 2020, the maturity of the 237 11^th Loan was extended to June 2021 and the 237 11^th Loan was amended to include a delayed draw facility of $4.25 million, which is being drawn now that most of the $3.6 million of remediation reserves we funded in connection with the amendment have been used. As of March 31, 2021, $2.8 million of the delayed draw funds had been drawn. We also funded an interest reserve account of $0.8 million which we are required to replenish over time. In conjunction with the amendment, a LIBOR floor of 50 basis points was put in place, the spread was increased by 25 basis points to 2.25% and the exit fee was increased by 50 basis points to 1.0%. At March 31, 2021, the 237 11^th Loan had a balance of $55.2 million and an effective interest rate of 2.75%. The 237 11^th Loan is non-recourse to us except for our environmental indemnity agreements, certain non-recourse carve-out and carry guaranties covering among other things interest and operating expenses, and in the case of the mortgage loan, a guaranty of 25% of the principal amount, decreasing to 10% of the principal balance upon the debt yield ratio becoming equal to or greater than 7.0%. The 237 11^th Loan is prepayable at any time in whole, and under certain circumstances in part, upon payment of a 0.50% deferred commitment fee (unless the loan is refinanced with the mortgage lender in which case no such fee is payable). We have signed a term sheet and expect to close, subject to normal closing conditions, on the refinancing of the acquisition loan prior to its maturity date.

From time to time, properties that we own, acquire or develop may experience defects, including concealed defects, or damage due to natural causes, defective workmanship or other reasons. In these situations, we pursue our rights and remedies as appropriate with insurers, contractors, sellers and others. Due to certain construction defects at 237 11^th that resulted in water penetration into the building and damage to certain apartment units and other property, which defects we believe were concealed and which would have required significant invasive work of a type not usually required or permitted, especially on a newly-built asset, to be detected, we submitted proofs of loss to our insurance carrier for property damage and business interruption (lost revenue) in March 2019. The insurance carrier subsequently disclaimed coverage for the losses and we filed a complaint against the carrier and its administrator, alleging that they breached the insurance policy by denying coverage and requesting a declaration that they are obligated to cover the claimed damage. We also filed legal claims against the seller, its parent company, and the general contractor to recover damages arising from the defective construction. In addition, the general contractor has impleaded into that litigation several subcontractors who performed work on the property. Management expects to recover some portion of the cost incurred to repair the property through the litigations and/or settlement negotiations with the seller, its parent company, the general contractor, the subcontractors, and the insurance carrier, although the amount of damages that may be recoverable in litigation and/or potential settlement negotiations are uncertain at this time, as is the receipt of any such payments, which has been impacted by the COVID-19 pandemic, including the resulting backlog in the court system and slowdown in judicial proceedings. We have been in discussions with the seller, its parent company, the general contractor, and the third-party defendants impleaded by the general contractor about engaging in mediation to potentially settle the case involving those parties. A mediation process commenced at the end of February 2021. We incurred significant cash outflows for costs associated with these repairs and remediation, which commenced in September 2019. Remediation and restoration work was delayed for two months in 2020 due to the temporary shutdown of non-essential construction projects in New York from April to June, which resulted in a delay in commencement of our leasing up of the property. Future delays would have a similar impact. As of March 31, 2021, remediation work on floors 3-12 had been completed, other than a few specific units. We expect the remediation and restoration project to be completed by summer 2021. As of March 31, 2021, 83 units had been remediated, many of which are now occupied. We also began leasing efforts for the remediated units and have seen an increase in traffic to view these units. Additional units will be introduced back into the market as they become available. During the three months ended March 31, 2021, we collected 100% of rent due. As of April 30, 2021, the property was approximately 43% leased.

77 Greenwich Construction Facility

In December 2017, we closed on a $189.5 million construction facility for 77 Greenwich (the “77 Greenwich Construction Facility”) with Massachusetts Mutual Life Insurance Company as lender and administrative agent (the “77 Greenwich Lender”). We draw down proceeds as costs related to the construction of the new mixed-use building are incurred. The balance of the 77 Greenwich Construction Facility was approximately $145.9 million at March 31, 2021. The 77 Greenwich Construction Facility has a four-year term ending January 2022 with an extension option for an additional year

Table of Contents

under certain circumstances. The collateral for the 77 Greenwich Construction Facility is the borrower’s fee interest in 77 Greenwich, as well as related collateral and a pledge of equity in the borrower. The 77 Greenwich Construction Facility bears interest on amounts drawn at a rate per annum equal to the greater of (i) LIBOR plus 8.25% and (ii) 9.25% (see Note 5 – Loans Payable and Secured Line of Credit to our consolidated financial statements for further discussion). The effective interest rate at March 31, 2021 and December 31, 2020 was 9.25%, respectively. Although there can be no assurances, we currently anticipate that the proceeds available under the 77 Greenwich Construction Facility, together with equity funded by us to date, will be sufficient to complete the construction and development of 77 Greenwich without us making any further equity contributions. In connection with the 77 Greenwich Construction Facility, we executed certain guaranties and environmental indemnities, including a recourse guaranty under which we are required to satisfy certain net worth and liquidity requirements. As of April 30, 2021, in connection with a potential refinancing of this loan, we have received several indicative offers from lenders across the debt stack.

In early April 2020, New York State required all non-essential construction projects be shut down due to the impact of the COVID-19 pandemic. As a result, the construction of 77 Greenwich was temporarily suspended. Construction recommenced mid-April, initially on a modified basis, as certain work was deemed “essential” construction. Since June 2020, a full crew has been on site and operating in accordance with applicable guidelines in response to the COVID-19 outbreak. Future delays in construction may result in a delay in our ability to complete the construction project on its original timeline and our ability to sell condominium units. We currently anticipate receiving our TCOs in stages throughout 2021, with our first TCO having been received on March 8, 2021.

On December 22, 2020, we entered into an amendment to the 77 Greenwich Construction Facility, pursuant to which, among other things, the sales pace covenants were amended and extended to provide for a reduction in the gross value of condominium sales at the 77 Greenwich and to afford more favorable cure rights than previously existed if a required sales threshold is not satisfied. We were in compliance with the April 1, 2021 sales pace covenant test and the sales pace covenant will be tested again on July 1, 2021 and October 2, 2021. Additionally, the outside date by which we are required to have substantially completed construction of all improvements to 77 Greenwich was extended to November 30, 2021 and the liquidity requirements will be reduced based on construction progress. We currently anticipate that TCOs, upon the granting of which, and in conjunction with our condominium offering plan being declared effective, unit purchasers may occupy their units, will be issued significantly sooner than such outside date, with the first TCO having been received on March 8, 2021. In connection with this amendment, we paid down $8.0 million of the 77 Greenwich Construction Facility and funded certain reserves to the 77 Greenwich Lender, a portion of which was funded by a release of certain cash collateral and the balance of which was funded by a mezzanine loan in accordance with the Mezzanine Loan Agreement defined below. Under the terms of this amendment, to the extent that any payments are needed to satisfy the minimum multiple fee owed to the 77 Greenwich Lender upon the repayment of the 77 Greenwich Construction Facility that have not already been paid, such minimum multiple fee will be reduced by 60% if the 77 Greenwich Construction Facility is repaid in full prior to June 30, 2021, and by 40% if repaid between July 1, 2021 and September 30, 2021. The Company currently expects any such payments to be minimal (if anything).

Mezzanine Loan

In December 2020, we entered into a mezzanine loan agreement with an affiliate of the CCF Lender (the “Mezzanine Loan Agreement”, and the loan thereunder, the “Mezzanine Loan”). The Mezzanine Loan is for an amount of $7.5 million and has a term of three years with two one-year extension options, exercisable under certain circumstances. The collateral for the Mezzanine Loan is the borrower’s equity interest in its direct, wholly-owned subsidiary, which owns 100% of the equity interests in the borrower under the 77 Greenwich Construction Facility. The blended interest rate for the 77 Greenwich Construction Facility and the Mezzanine Loan, assuming the 77 Greenwich Construction Facility and the Mezzanine Loan are fully drawn, is 9.44% on an annual basis, representing a variance from the prior rate of approximately 19 basis points. Interest on the Mezzanine Loan is not payable on a monthly basis but instead is automatically added to the unpaid principal amount on a monthly basis (and therefore accrues interest) and is payable in full on the maturity date of the Mezzanine Loan. Upon final repayment of the Mezzanine Loan, a MOIC will be due on substantially the same terms as provided for in the Corporate Credit Facility. The Mezzanine Loan may not be prepaid prior to prepayment in full of the 77 Greenwich Construction Facility, but if the 77 Greenwich Construction Facility is being prepaid in full, the Mezzanine Loan may be prepaid simultaneously therewith. Subject to the prior sentence the Mezzanine Loan may be prepaid in whole or in part, without penalty or premium (other than payment of the MOIC amount, if applicable, as provided above), upon prior written notice to the lender under the Mezzanine Loan. In connection with the Mezzanine Loan, the Company entered into a completion guaranty, carry guaranty, equity funding guaranty, recourse guaranty and

Table of Contents

environmental indemnification undertaking substantially consistent with the Company’s existing guarantees made to the 77 Greenwich Lender in connection with the 77 Greenwich Construction Facility.

Secured Line of Credit

Our $12.75 million secured line of credit with Sterling National Bank is secured by the Paramus, New Jersey property. In March 2021, we entered into an amendment to extend the maturity date to March 2022. The secured line of credit, which prior to the amendment, bore interest at 200 basis points over the 30-day LIBOR, now bears interest at the prime rate, currently 3.25%. The secured line of credit is pre-payable at any time without penalty. As of March 31, 2021, the secured line of credit had an outstanding balance of $8.95 million and an effective interest rate of 3.25%.

The Berkley Loan

We own a 50% interest in a joint venture formed to acquire and operate The Berkley. In December 2016, the joint venture closed on the acquisition of The Berkley through a wholly-owned special purpose entity for a purchase price of $68.885 million, of which $42.5 million was financed through a 10-year loan (the “Berkeley Loan”) secured by The Berkley, and the balance was paid in cash, half of which was funded by us. On February 28, 2020, in connection with a refinancing, the Berkley Loan was repaid in full and it was replaced with a new 7-year, $33.0 million loan (the “New Berkley Loan”) which bears interest at a fixed rate of 2.717% and is interest only during the initial five years. It is pre-payable at any time and can be increased by up to $6.0 million under certain circumstances. We and our joint venture partner are joint and several recourse carve-out guarantors under the New Berkley Loan.

250 North 10^th Note

We own a 10% interest in a joint venture with TF Cornerstone (the “250 North 10^th JV”) formed to acquire and operate 250 North 10^th, a recently built 234-unit apartment building in Williamsburg, Brooklyn, New York. On January 15, 2020, the 250 North 10^th JV closed on the acquisition of the property through a wholly-owned special purpose entity for a purchase price of $137.75 million, of which $82.75 million was financed through a 15-year mortgage loan (the “250 North 10^thNote”) secured by 250 North 10^th and the balance was paid in cash. Our share of the equity totaling approximately $5.9 million was funded through a loan (the “Partner Loan”) from our joint venture partner. The Partner Loan bears interest at 7.0% and is prepayable any time within its four year term. Our partner has the option of having the Partner Loan repaid in our common stock if the price of our common stock exceeds $6.50 per share at the time of conversion. The non-recourse 250 North 10^th Note bears interest at 3.39% for the duration of the loan term and has covenants, defaults, and a non-recourse carve out guaranty executed by us. We earned an acquisition fee at closing and are entitled to ongoing asset management fees and a promote upon the achievement of certain performance hurdles.

COVID-19 Pandemic, Liquidity and Going Concern

At this time, we believe our existing balances of cash and cash equivalents, together with proceeds that may be raised from debt issuances, equity issuances, dispositions of properties, sales of partial interests in properties and/or draws on our Corporate Credit Facility and secured line of credit will be sufficient to satisfy our working capital needs and projected capital and other expenditures associated with our operations over the next 12 months, including approximately $300,000 of anticipated capital expenditures primarily at 237 11th. We believe we have good relationships with our lenders and we have historically negotiated extensions, amendments and waivers with our lenders, when warranted.

Given the impacts of COVID-19, it is possible that we may be unable to extend or refinance maturing debt, including the 237 11^th Loan (as defined in Note 5 - Loans Payable and Secured Line of Credit to our consolidated financial statements) which matures in June 2021, or meet future sales pace covenants under the amended 77 Greenwich Construction Facility (as defined in Note 5 - Loans Payable and Secured Line of Credit to our consolidated financial statements) which matures in January 2022, creating substantial doubt about our ability to continue as a going concern. Although we believe that we will be able to enter into extensions, amendments and waivers with our lenders, raise additional capital, refinance indebtedness or enter into other financing arrangements or engage in asset sales sufficient to fund any cash needs that we are not able to satisfy with our cash, cash equivalents and draws on our Corporate Credit Facility or secured line of credit, given the current environment there can be no assurance that we will be able to do so on terms satisfactory to us, if at all. See Note 1 – Business - COVID-19 Pandemic; Liquidity and Going Concern to our consolidated financial statements for further information.

Table of Contents

At-The-Market Equity Offering Program

In December 2016, we entered into an "at-the-market" equity offering program (the “ATM Program”), to sell up to an aggregate of $12.0 million of our common stock. There were no sales during the periods presented.

Cash Flows

Cash Flows for the Three Months Ended March 31, 2021 Compared to the Three Months Ended March 31, 2020

Net cash used in operating activities decreased by approximately $2.5 million to $1.9 million for the three months ended March 31, 2021 from $4.4 million for the three months ended March 31, 2020. This decrease was mainly due to an increase in accounts payable and accrued expenses of $3.7 million over the same period last year, partially offset by an increase in prepaid expenses and other assets, net of $695,000 over the same period last year.

Net cash used in investing activities decreased by approximately $7.9 million to $12.2 million for the three months ended March 31, 2021 from $20.1 million for the three months ended March 31, 2020. The decrease in cash used in investing activities was primarily due to our investment in our joint venture for The Berkley in connection with the pay-down of $5.4 million in debt during the three months ended March 31, 2020 as well as $6.0 million less in net additions to real estate this period compared to the same period last year, partially offset by $3.5 million of deferred real estate deposits on the condominium during the three months ended March 31, 2020.

Net cash provided by financing activities decreased by approximately $21.9 million to $9.8 million for the three months ended March 31, 2021 from $31.7 million for the three months ended March 31, 2020. The decrease in cash provided by financing activities primarily relates to the $6.9 million and $2.1 million in borrowings from the 77 Greenwich Construction Facility and the 237 11^th Loan, respectively, during the three months ended March 31, 2021 as compared to borrowing $34.0 million and $13.9 million in proceeds from the Corporate Credit Facility and 77 Greenwich Construction Facility, respectively, during the three months ended March 31, 2020. We also borrowed $1.2 million from the secured line of credit during the three months ended March 31, 2021 as compared to repaying the $15.4 million 237 11^th mezzanine loan during the three months ended March 31, 2020.

Net Operating Losses

We believe that our U.S. federal NOLs as of the emergence date of the Syms bankruptcy were approximately $162.8 million and believe our U.S. federal NOLs as of March 31, 2021 were approximately $236.3 million. In connection with the conveyance of the school condominium to the SCA, we applied approximately $11.6 million of federal NOLs against taxable capital gains of approximately $18.5 million. Since 2009 through March 31, 2021, we have utilized approximately $23.9 million of the federal NOLs. Pursuant to the TCJA, corporate alternative minimum tax (“AMT”) credit carryforwards are eligible for a 50% refund in tax years 2018 through 2020, and beginning in tax year 2021, any remaining AMT credit carryforwards are 100% refundable. As a result of these new rules, we had released our valuation allowance of $3.1 million in 2017 which was formerly reserved against our AMT credit carryforwards. We had recorded a tax benefit and refund receivable of $3.1 million in 2017 in connection with this valuation allowance release. We received approximately $1.6 million of the refund receivable in October 2019 and the balance of approximately $1.5 million in July 2020.

On March 27, 2020, the “Coronavirus Aid, Relief, and Economic Security (CARES) Act” was signed into law. The CARES Act accelerated the ability of corporations to recover AMT credits, permitting a full refund for tax years 2018 and 2019. The CARES Act also included provisions relating to refundable payroll tax credits, deferral of employer side social security payments, net operating loss carrybacks and carryforwards, modifications to the net interest deduction limitations, increased limitations on qualified charitable contributions, and technical corrections to tax depreciation methods for qualified improvement property. It also appropriated funds for the SBA Paycheck Protection Program loans that are forgivable in certain situations to promote continued employment, as well as Economic Injury Disaster Loans to provide liquidity to small businesses harmed by COVID-19. Management is monitoring the impact that the CARES Act may have on the Company. The CARES Act did not have a material impact on our financial position, results of operations, or cash flows for three months ended March 31, 2021 and the year ended December 31, 2020.

Table of Contents

Based on management’s assessment, it is more likely than not that the entire deferred tax assets will not be realized by future taxable income or tax planning strategies. Accordingly, a valuation allowance of $62.4 million was recorded as of March 31, 2021.

We believe that certain of the transactions that occurred in connection with our emergence from bankruptcy in September 2012, including the rights offering and the redemption of the Syms shares owned by the former majority shareholder of Syms in accordance with the plan of reorganization, resulted in us undergoing an “ownership change,” as that term is used in Section 382 of the Code. However, while the analysis is complex and subject to subjective determinations and uncertainties, we believe that we should qualify for treatment under Section 382(l)(5) of the Code. As a result, we believe that our NOLs are not subject to an annual limitation under Section 382. However, if we were to undergo a subsequent ownership change in the future, our ability to utilize our NOLs could be subject to limitation under Section 382. In addition, the TCJA limited the deductibility of NOLs arising in tax years beginning after December 31, 2017 to 80 percent of taxable income (computed without regard to the net operating loss deduction) for the taxable year. However, the CARES Act suspended the 80% limitation on the use of NOLs for tax years beginning before January 1, 2021, and allowed losses arising in taxable years beginning after December 31, 2017 and before January 1, 2021 to be carried back up to five years.

Even if all of our regular U.S. federal income tax liability for a given year is reduced to zero by virtue of utilizing our NOLs, we may still be subject to state, local or other non-federal income taxes.

Our certificate of incorporation includes a provision intended to help preserve certain tax benefits primarily associated with our NOLs. This provision generally prohibits transfers of stock that would result in a person or group of persons becoming a 4.75% stockholder, or that would result in an increase or decrease in stock ownership by a person or group of persons that is an existing 4.75% stockholder.

Cautionary Note Regarding Forward-Looking Statements

This Quarterly Report on Form 10-Q, including information included or incorporated by reference in this Quarterly Report on or any supplement to this Quarterly Report, may include forward-looking statements within the meaning of Section 27A of the Securities Act of 1933, as amended and the Securities Exchange Act of 1934, as amended (the “Exchange Act”), and information relating to us that are based on the beliefs of management as well as assumptions made by and information currently available to management. These forward-looking statements include, but are not limited to, statements about our plans, objectives, expectations and intentions that are not historical facts, and other statements identified by words such as “may,” “will,” “expects,” “believes,” “plans,” “estimates,” “potential,” or “continues,” or the negative thereof or other and similar expressions. In addition, in some cases, you can identify forward-looking statements by words or phrases such as “trend,” “potential,” “opportunity,” “believe,” “comfortable,” “expect,” “anticipate,” “current,” “intention,” “estimate,” “position,” “assume,” “outlook,” “continue,” “remain,” “maintain,” “sustain,” “seek,” “achieve,” and similar expressions. Such statements reflect our current views with respect to future events, the outcome of which is subject to certain risks, including among others:

●

the impact of COVID-19;

●

our limited cash resources, generation of minimal revenues from operations, and our reliance on external sources of financing to fund operations in the future;

●

our ability to execute our business plan, including as it relates to the development of our largest asset, 77 Greenwich;

●

risks associated with our debt, including the risk of default on our obligations, including repayment, and debt service requirements;

●

risks associated with covenant restrictions in our loan documents that could limit our flexibility to execute our business plan;

●

adverse trends in the New York City residential condominium market;

●

general economic and business conditions, including with respect to real estate, and their effect on the New York City real estate market in particular;

Table of Contents

●

our ability to obtain additional financing and refinance existing loans and on favorable terms;

●

our investment in property development may be more costly than anticipated and investment returns from our properties planned to be developed may be less than anticipated;

●

our ability to enter into new leases and renew existing leases with tenants at our commercial and residential properties;

●

we may acquire properties subject to unknown or known liabilities, with limited or no recourse to the seller;

●

risks associated with the effect that rent stabilization regulations may have on our ability to raise and collect rents;

●

competition for new acquisitions and investments;

●

risks associated with acquisitions and investments in owned and leased real estate;

●

risks associated with joint ventures;

●

our ability to maintain certain state tax benefits with respect to certain of our properties;

●

our ability to obtain required permits, site plan approvals and/or other governmental approvals in connection with the development or redevelopment of our properties;

●

costs associated with complying with environmental laws and environmental contamination, as well as the Americans with Disabilities Act or other safety regulations and requirements;

●

loss of key personnel;

●

the effects of new tax laws;

●

our ability to utilize our NOLs to offset future taxable income and capital gains for U.S. Federal, state and local income tax purposes;

●

risks associated with current political and economic uncertainty, and developments related to the outbreak of contagious diseases;

●

risks associated with breaches of information technology systems;

●

stock price volatility and other risks associated with a lightly traded stock;

●

stockholders may be diluted by the issuance of additional shares of common stock or securities convertible into common stock in the future;

●

a declining stock price may make it more difficult to raise capital in the future;

●

the influence of certain significant stockholders;

●

limitations in our charter on transactions in our common stock by substantial stockholders, designed to protect our ability to utilize our NOLs and certain other tax attributes, may not succeed and/or may limit the liquidity of our common stock;

●

certain provisions in our charter documents and Delaware law may have the effect of making more difficult or otherwise discouraging, delaying or deterring a takeover or other change of control of us;

●

certain provisions in our charter documents may have the effect of limiting our stockholders’ ability to obtain a favorable judicial forum for certain disputes; and

●

unanticipated difficulties which may arise and other factors which may be outside our control or that are not currently known to us or which we believe are not material.

Table of Contents

In evaluating such statements, you should specifically consider the risks identified under the section entitled “Risk Factors” in our 2020 Annual Report for the year ended December 31, 2020, as filed with the Securities and Exchange Commission (the “SEC”) on March 31, 2021, and under the section entitled “Risk Factors” in this Quarterly Report on Form 10-Q, any of which could cause actual results to differ materially from the anticipated results. Should one or more of these risks or uncertainties materialize, or should underlying assumptions prove incorrect, actual results or outcomes may vary materially from those contemplated by any forward looking statements. Subsequent written and oral forward-looking statements attributable to us or persons acting on our behalf are expressly qualified in their entirety by the cautionary statements in this paragraph and elsewhere described in our 2020 Annual Report, this Form 10-Q and other reports filed with the SEC. All forward-looking statements speak only as of the date of this Form 10-Q or, in the case of any documents incorporated by reference in this Form 10-Q, the date of such document, in each case based on information available to us as of such date, and we assume no obligation to update any forward-looking statements, except as required by law.

Item 3. Quantitative and Qualitative Disclosures about Market Risk

As a smaller reporting company, we are not required to provide the disclosure required by this Item.

Item 4. Controls and Procedures

a)Evaluation of Disclosure Controls and Procedures

We maintain disclosure controls and procedures that are designed to ensure that information required to be disclosed in our Exchange Act reports is recorded, processed, summarized and reported within the time periods specified in the SEC’s rules and forms, and that such information is accumulated and communicated to our management, including our Chief Executive Officer (the “CEO”) and Chief Financial Officer (the “CFO”), as appropriate, to allow timely decisions regarding required disclosure based closely on the definition of “disclosure controls and procedures” in Rule 13a-15(e) of the Exchange Act. Notwithstanding the foregoing, a control system, no matter how well designed and operated, can provide only reasonable, not absolute, assurance that it will detect or uncover failures within the Company to disclose material information otherwise required to be set forth in our periodic reports.

Our management, with the participation of our CEO and CFO, evaluated the effectiveness of our disclosure controls and procedures (as defined in Rules 13a-15(e) and 15d-15(e) promulgated under the Exchange Act) as of the end of the period covered by this Quarterly Report on Form 10-Q. Based on this evaluation, the CEO and CFO concluded that as of the end of the period covered by this Quarterly Report on Form 10-Q, our disclosure controls and procedures were effective to give reasonable assurance to the timely collection, evaluation and disclosure of information relating to the Company what would potentially be subject to disclosure under the Exchange Act and the rules and regulations promulgated thereunder.

b)Internal Control Over Financial Reporting

There have been no changes in our internal control over financial reporting during the period from January 1, 2021 to March 31, 2021 that have materially affected, or are reasonably likely to materially affect, our internal control over financial reporting.

PART II. OTHER INFORMATION

Item 1. Legal Proceedings

In the normal course of business, we are party to routine legal proceedings. Based on advice of counsel and available information, including current status or stage of proceeding, and taking into account accruals where they have been established, management currently believes that any liabilities ultimately resulting from litigation we are currently involved in will not, individually or in the aggregate, have a material adverse effect on our consolidated financial position, results of operations or liquidity.

Table of Contents

Item 1A. Risk Factors

There have been no material changes in our risk factors disclosed in Part I, Item 1A, of our 2020 Annual Report.

Item 2. Unregistered Sales of Equity Securities and Use of Proceeds

Recent Sales of Unregistered Securities

None.

Issuer Purchases of Equity Securities

The following table shows the stock repurchase activity by the Company or any “affiliated purchaser” of the Company, as defined in Rule 10b-18(a)(3) under the Exchange Act, by month for the three months ended March 31, 2021:


					Total	Approximate
					number of	Dollar Value of
			Average		Shares Purchased	Shares that May
	Total		Price		As Part of Publicly	Yet Be Purchased
	Number of		Paid		Announced	Under the
Period	Shares Purchased		per Share		Plans or Programs	Plans or Programs
1/1/21 - 1/31/21	10,000		$	1.40	—		4,516,639
2/1/21 - 2/28/21	—			—	—		4,516,639
3/1/21 - 3/31/21	—			—	—		4,516,639

Quarter ending March 31, 2021 (1)	10,000	(2)	$	1.40	—	$	4,516,639	(3)

(1)In December 2019, our Board of Directors approved a share repurchase program under which we can purchase up to $5.0 million of shares of our common stock, which is subject to the terms of our Corporate Credit Facility. Repurchases under the stock repurchase program may be made through open market or privately negotiated transactions at times and on such terms and in such amounts as management deems appropriate, subject to market conditions, regulatory requirements and other factors. The program does not obligate the Company to repurchase any particular amount of common stock, and may be suspended or discontinued at any time without notice.

(2)Includes 10,000 shares purchased by an affiliated purchaser of the Company.

(3)Since inception of the share repurchase program through March 31, 2021, the Company has repurchased 250,197 shares of common stock for approximately $483,361, or an average price per share of $1.93. As of March 31, 2021, approximately $4.5 million of shares remained available for purchase under the share repurchase program, subject to the terms of our Corporate Credit Facility.

Item 3. Defaults Upon Senior Securities

None.

Item 4. Mine Safety Disclosures

Not Applicable.

Item 5. Other Information

None.

Table of Contents

Item 6. Exhibits


	3.1	Amended and Restated Certificate of Incorporation of Trinity Place Holdings Inc. (incorporated by reference to Exhibit 3.1 of the Form 8-K filed by us on February 13, 2015).

	3.2	Bylaws of Trinity Place Holdings Inc. (incorporated by reference to Exhibit 3.2 of the Form 8-K filed by us on September 19, 2012).

	31.1*	Certification of Chief Executive Officer pursuant to Rule 13a-14(a) under the Securities and Exchange Act of 1934, as adopted pursuant to Section 302 of the Sarbanes-Oxley Act of 2002.

	31.2*	Certification of Chief Financial Officer pursuant to Rule 13a-14(a) under the Securities and Exchange Act of 1934, as adopted pursuant to Section 302 of the Sarbanes-Oxley Act of 2002.

	32.1**	Certification of Chief Executive Officer pursuant to Rule 13a-14(b) under the Securities and Exchange Act of 1934 and 18.U.S.C. Section 1350, as adopted pursuant to Section 906 of the Sarbanes-Oxley Act of 2002.

	32.2**	Certification of Chief Financial Officer pursuant to Rule 13a-14(b) under the Securities and Exchange Act of 1934 and 18.U.S.C. Section 1350, as adopted pursuant to Section 906 of the Sarbanes-Oxley Act of 2002.

	101*	The following materials from our Quarterly Report on Form 10-Q for the period ended March 31, 2021 formatted as inline XBRL (eXtensible Business Reporting Language): (i) Consolidated Balance Sheets as of March 31, 2021 (unaudited) and December 31, 2020 (audited), (ii) Consolidated Statements of Operations and Comprehensive Loss for the three months ended March 31, 2021 (unaudited) and March 31, 2020 (unaudited), (iii) Consolidated Statements of Stockholders’ Equity for the three months ended March 31, 2021 (unaudited) and March 31, 2020 (unaudited), (iv) Consolidated Statements of Cash Flows for the three months ended March 31, 2021 (unaudited) and three months ended March 31, 2020 (unaudited), (v) Notes to Consolidated Financial Statements (unaudited) and (vi) Cover Page Interactive Data File.

	104*	Cover Page Interactive Data File (formatted as inline XBRL and contained in Exhibit 101)

*	Filed herewith

**	Furnished herewith

Table of Contents

SIGNATURES

Pursuant to the requirements of the Securities Exchange Act of 1934, the registrant has duly caused this report to be signed on its behalf by the undersigned thereunto duly authorized.


	TRINITY PLACE HOLDINGS INC.

Date: May 12, 2021	By	/s/ Matthew Messinger
		MATTHEW MESSINGER
		PRESIDENT and CHIEF EXECUTIVE OFFICER
		(Principal Executive Officer)

Date: May 12, 2021	By	/s/ Steven Kahn
		STEVEN KAHN
		CHIEF FINANCIAL OFFICER
		(Principal Financial Officer)